Active SLED Opportunity · ILLINOIS · CITY OF NAPERVILLE, IL
AI Summary
City of Naperville seeks bids for electric equipment painting services including welding, patching, prepping, and painting of substation and distribution electrical equipment. Contract term through 2027 with renewal options. Bidders must have 10+ years experience and comply with safety and prevailing wage laws. Virtual pre-bid meeting and electronic bid submission required.
The bid will establish service rates and material rates/material markup percentage/material discount percentage that are all inclusive (i.e. no additional fuel surcharges, shipping fees, etc.). Estimated quantities are for bid purposes only. Total quantities shall be determined by the City of Naperville Department of Electric Utility based upon actual need .
| Release Bid Date / Advertised: | July 16, 2026 |
| Pre-Bid Meeting (Non-Mandatory): | July 23, 2026, 10:30am Microsoft Teams meeting |
| Question Submission Deadline: | July 27, 2026, 12:00pm |
| Question Response Deadline: | July 28, 2026, 12:00pm |
| Bid Opening: | August 14, 2026, 2:00pm |
Contractor shall perform all Work in accordance with this Contract. Contractor shall furnish all materials, equipment, tools, and labor which is reasonably and properly inferable and necessary for the proper completion of the Work, whether specifically indicated in this Contract.The bid will establish service rates and material rates/material markup percentage/material discount percentage that are all inclusive (i.e. no additional fuel surcharges, shipping fees, etc.). Estimated quantities are for bid purposes only. Total quantities shall be determined by the City of Naperville Department of Electric Utility based upon actual need.
THE GENERAL TERMS AND CONDITIONS WHICH FOLLOW APPLY TO ALL PURCHASES AND BECOME A DEFINITE PART OF EACH FORMAL INVITATION TO BID, PURCHASE ORDER, OR CONTRACT ISSUED BY THE CITY OF NAPERVILLE, UNLESS OTHERWISE SPECIFIED. BY SUBMITTING A BID, THE BIDDER AGREES TO BE BOUND BY THESE TERMS AND CONDITIONS. BIDDERS OR THEIR AUTHORIZED REPRESENTATIVES ARE EXPECTED TO FULLY INFORM THEMSELVES OF THE CONDITIONS, REQUIREMENTS, AND SPECIFICATIONS BEFORE SUBMITTING BIDS, FAILURE TO DO SO WILL BE AT THE BIDDER'S OWN RISK AND HE CANNOT SECURE RELIEF ON THE PLEA OF ERROR.
The first three items must be performed by the bidder in order for the bid submittal to qualify for consideration by the City.
The bid will establish service rates and material rates/material markup percentage/material discount percentage that are all inclusive (i.e. no additional fuel surcharges, shipping fees, etc.). Estimated quantities are for bid purposes only. Total quantities shall be determined by the City of Naperville Department of Electric Utility based upon actual need .
Title: EU Electric Equipment Painting
Bid No: 26-159
Bid Due Date/Time: Friday, August 14, 2026, 2:00 pm
“Contractor” means the company, employees, or agents proposing to provide rehabilitation services to the City of Naperville. “City” shall mean the City of Naperville, its employees, or agents.
A Non-Mandatory Pre-Bid Meeting will be held on Thursday, July 23, 2026 at 10:30 am virtually via Microsoft Teams.This is your only opportunity to speak directly with staff from the Public Utilities (Electric) | DPU-E regarding the project.
Microsoft Teams meeting
Join: https://teams.microsoft.com/meet/216938517484064?p=B4HvC5KR6IOA6ktRdb
Meeting ID: 216 938 517 484 064
Passcode: wb6ci3ah
Dial in by phone
+1 630-733-1095,,375115340# United States, Big Rock
Phone conference ID: 375 115 340#
For organizers: Meeting options | Reset dial-in PIN
Bidders are responsible for becoming familiar with all conditions, instructions, and contract documents governing this bid and shall inspect the site and conditions pertinent to the work involved. Submission of a bid will be considered specific evidence of having performed the above. Failure to make such an inspection shall not excuse the Contractor from performance of the duties and obligations imposed under the terms of the contract. Once the award has been made, failure to have read all the conditions, instructions, and specifications of this contract shall not be cause to alter the original contract or to request additional compensation.
All questions concerning this bid shall be submitted in writing prior to the question due date. The deadline for questions is Monday, July 27, 202612:00 pm If required, a written response in the form of an addendum will be issued no later than Tuesday, July 28, 202612:00 pm. No contact with the Public Utilities (Electric) | DPU-Eshall be made during the bid process. Questions asked after the deadline are not guaranteed a response.
Shanel Gayle, Procurement Officer
Bids must be accompanied by an Affidavit of Compliance, provided in this package, and shall be submitted on the forms provided or in an identical format typed by the bidder, properly signed in the appropriate places, and submitted electronically via the City’s e-bidding service.
To attend the Virtual Bid Opening on your computer or mobile app: Click here to join the meeting Or call in (audio only) +1 630-733-1095. Phone Conference ID: 146 781 798# approximately 5 minutes prior to the Due Date/Time. Attendees should join approximately 5 minutes prior to the Due Date/Time.
Due at Bid Opening:
Due Before Award:
Due within thirty (30) days of Award:
If you choose not to respond, please select NO BID on https://procurement.opengov.com/portal/naperville.
When a bid deposit is required as indicated on the Invitation to Bid, each bid must be accompanied by a bid bond signed by a surety company authorized to do business in Illinois. For construction projects the bid deposit shall be in an amount equal to at least 10% of the amount of the bid. Any bid deposit shall be in an amount equal as indicated in the Invitation to Bid.
The City of Naperville Procurement Services and its e-Procurement Portal https://procurement.opengov.com/portal/naperville are the only authorized sources of solicitation documents. Solicitation documents and forms obtained from any other source may be an incomplete set of documents. Reproduction of these documents without the express permission of the City of Naperville is prohibited.
The City of Naperville has developed a new portal for vendors to register and update existing information within Civic Access. The City of Naperville will only accept vendor forms from vendors currently working with the Procurement and/or Accounts Payable teams. It will allow you to:
How do I register?
This is an “electronic bid,” meaning that bids must be submitted via the City’s e-bidding service, OpenGov, in electronic format. All bids submitted must be received electronically via the City’s e-bidding service before the time specified for opening the bid. A link to the City’s e-bidding service is available on the City’s website at https://www.naperville.il.us/government/city-finances/purchasing-and-bids/.
Downloading documents and submitting bids requires registration with OpenGov. If you aren’t already a member, you can get a FREE SUBSCRIPTION to the City of Naperville account by going to https://procurement.opengov.com/signup. Any incomplete submittals may be rejected as non-responsive.
The Procurement Manager, or their designated agent, will decide when the specified time for the bid opening has arrived (as determined by the clock on the e-bidding system), and bids will be opened precisely at the assigned time. Formal sealed bids, amendments thereto, or requests for withdrawal of bids after the time specified for the bid opening will not be considered.
Bidders shall acknowledge the receipt of any addendum interpreting the specifications.
Samples or drawings requested shall be delivered free of charge with the bid. Rejected samples shall be removed by the bidder at his own expense after the bid opening. Accepted samples will be retained during the life of the contract.
In the event you cannot submit a bid, please submit the no bid section within the City’s e-procurement platform.
Where required, the Contractor is responsible for obtaining all necessary licenses, permits, or certifications required to conduct business in the City of Naperville and essential for supporting the bid scope and successful project results. Some licenses may be obtainable through the City Clerk’s Office and shall be provided at the time of bid submittal. The Contractor shall supply copies of all required licenses upon award.
All questions concerning the bid shall be submitted to the Procurement Services Team. Questions requiring a clarification or interpretation of the specifications shall be submitted to the Procurement Department in writing at least five working days prior to the bid opening so that the Procurement Department can issue a written response to all bidders in the form of an addendum. Whenever the answer to a question is contained in the bid documents, the bidder shall be directed to the provision in the specifications which responds to the question. The City of Naperville, Illinois will not be responsible for any other explanation of the specifications made prior to the receipt of bids.
This contract calls for the construction of a “public work” within the meaning of the Illinois Prevailing Wage Act (820 ILCS 130/1-12 et seq.). Contractors and subcontractors shall comply with the requirements of the Illinois Prevailing Wage Act including, but not limited to, all wage requirements and notice and recordkeeping duties including paying laborers, workers and mechanics performing work under this contract no less than the currently prevailing rate of wages in the county where the work is performed and filing a copy of the certified payroll with the public body in charge of the project as well as the State; see link below for additional details.
The Contractor is advised that the Illinois Department of Labor (IDOL) revises the prevailing wage rates and the Contractor/subcontractor has an obligation to check the IDOL website for revisions to prevailing wage rates. For information regarding the current prevailing wage rates, please refer to the DOL website: https://www2.illinois.gov/idol/laws-rules/conmed/pages/prevailing-wage-rates.aspx. If IDOL revises the prevailing rates of wage during the term of the contract, the Contractor/subcontractor is required to pay the then current prevailing rate of rages. Any increases in costs to the Contractor due to changes in the prevailing rate of wage during the term of any contract shall be at the expense of the Contractor and not at the expense of the Owner.
The Contractor shall defend and hold harmless the City, for any claim, suit or action, including costs of defense, expert witness and attorney fees, either at law, equity or in an administrative proceeding, arising from any alleged violation of the Prevailing Wage Act. The requirements of this Section shall survive the termination of the Agreement formed hereunder.
Pursuant to PA 100-1177 and in accordance with 820 ILCS 130/5.1, the Illinois Department of Labor (DOL) launched the Certified Transcript of Payroll Portal and contractors are now required to submit all of their certified payroll documentation to the State rather than local government agencies. Certified Payroll must have the bid number clearly identified. The link to the DOL portal is below:
https://www2.illinois.gov/idol/Laws-Rules/CONMED/Pages/certifiedtranscriptofpayroll.aspx
Contractor agrees to comply with the Employment of Illinois Workers on Public Works Act (30 ILCS 570/0.01 et seq.) and employ Illinois laborers if, at the time this contract is executed or during the term of this contract, there is excessive unemployment in Illinois as defined in the Act. To review the statute, please click on the link found here.
CURRENT UPDATE IN EFFECT:
The Employment of Illinois Workers on Public Works Act is Currently in Effect.
The Employment of Illinois Workers on Public Works Act requires contractors to use at least 90% Illinois laborers on all public works projects that receive State funds or funds administered by the State during a period of excessive unemployment. 30 ILCS 570/3. A period of excessive unemployment means any month immediately following 2 consecutive calendar months when the Illinois unemployment rate exceeds 5%. 30 ILCS 570/1(2).
Please be aware that the Act has now come into effect as the unemployment rate in Illinois has exceeded 5% (according to the US Bureau of Labor Statistics) for two consecutive months. The unemployment rates for March (revised) and April were 5.1%.
Under the Act, an Illinois laborer is anyone who has resided in the state for at least 30 days with the intent to become or remain an IL resident. 30 ILCS 570/1(1).
For additional information about the Act, please visit IDOL’s website.
Unless the proposal form states that an alternate proposal is permissible, each vendor may submit only ONE proposal. If an unsolicited alternate is included in the bid, only the first proposal seen by the City will be read and considered.
The Contractor shall not be allowed to subcontract the work under this agreement without the written consent of the City of Naperville. If approved, the subcontractor(s) shall be bound by the conditions of the agreement between the City of Naperville and the Contractor and shall perform his/her work in accordance with all terms of this agreement and specifications.
A party who has quoted prices for work, materials, or supplies to a bidder is not thereby disqualified from quoting prices to other bidders or from submitting a bid directly for the work, materials, or supplies.
The successful bidder must be in compliance with State of Illinois HB-1855 (Public Act 095-0635), which amends the Prevailing Wage Act. Before an employer commences work on a public works project, the employer shall have in place a written program which meets or exceeds the program requirements in this Act, to be filed with the public body engaged in the construction of the public works and made available to the general public, for the prevention of substance abuse among its employees. The testing must be performed by a laboratory that is certified for Federal Workplace Drug Testing Programs by the Substance Abuse and Mental Health Service Administration of the U.S. Department of Health and Human Services.
Unless otherwise specified in the specifications, all formal bids submitted shall be binding for ninety (90) calendar days following date of opening.
The Contractor shall exercise all necessary caution to protect pedestrian traffic and to protect all public and private property from injury or damage caused by the Contractor’s operations. Any practice deemed hazardous by designated or other qualified City staff shall be immediately halted upon verbal or written notification. The Contractor shall comply with all OSHA, NIOSH, and other applicable federal, state, and local regulations, codes, and/or ordinances. In addition, the contractor shall protect all interior areas that are not impacted by work.
A written request for the withdrawal of a bid will be granted if the request is received by the City prior to the specified time of opening.
Contractor acknowledges that the Freedom of lnformation Act, 5 ILCS 140/1 et seq. (the "ACT") places an obligation on the City to produce certain records that may be in possession of the Contractor. Contractor shall comply with the retention and documentation requirements of the Local Records Retention Act 50 ILCS 205/1 et seq. and the Act and shall maintain all records relating to this Agreement in compliance with the Local Records Retention Act (complying in all respects as if the Contractor was, in fact, the City). Upon notice from the City, Contractor shall review its records promptly and produce to the City within two business days of said notice from the City the required documents which are responsive to a request under the Act. If additional time is necessary to comply with the request, the Contractor may request the City to extend the time to do so, and the City will, if time and a basis for extension under the Act permits, consider such extensions. In the event Contractor fails to produce the requested records or fails to produce the requested records within the time period required above and the City is assessed a fine, fee or penalty for failure to timely comply with Act do to Contractor’s actions, Contractor shall reimburse City for all fines, fee or penalties, including reasonable attorney’s fees, paid by the City.
Prior to the start of any work, the Contractor and the Jobsite Manager/Supervisor will be required to complete the City’s Contractor Safety Orientation Checklist at a pre-construction meeting. No work can begin until the completed form has been received and signed by the Jobsite Manager/Supervisor. A sample of the Contractor Safety Orientation Checklist is included as part of the bid document.
At the time assigned for the opening of formal bids, the bids will be opened and read aloud. Bidders are encouraged to attend all openings and to offer constructive suggestions for improvements to the bid format or any way in which greater savings can be realized in future bidding opportunities.
The City of Naperville intends to award a contract to the responsible bidder submitting the lowest responsive bid. Lowest price shall be determined by the Total Bid amount listed on the Bid Worksheet resulting from multiplying the actual number of acceptable units by the unit price items incorporated into the work or service, all as set forth in bid worksheet. In addition, if requested within bid documents, the City may elect to include, within the Total Bid, any combination of additive, alternate, or optional Bid items for which the City determines funds will be available at the time of award. The City will review and make adjustments associated with arithmetic errors to ascertain whether the order of bids is correct. In the event of arithmetic errors in any of the line items, the unit price will be the controlling factor to correct the arithmetic error. The City will not assume that the error exists in the unit price.
Bids submitted are offers only and the decision to accept or reject is a function of quality, reliability, capability, reputation, and expertise of the bidders. The City reserves the right to reject any and all bids or to waive any non-conformity in bids received whenever such rejection or waiver is in the best interests of the City. The City also reserves the right to reject the bid of a bidder who has previously failed to satisfactorily perform a contract, has not completed contracts on time, or whom investigation shows is not in a position to perform the contract. The City of Naperville reserves the right to award individual bids to more than one vendor if it is deemed to be in the best interest of the City. The City reserves the right to increase or decrease the contract quantity without penalty from the contractor to the City.
The following is the process of awarding the bid.
The contract will be awarded to the lowest responsible bidder, or any other bidder determined by the City Council to be in the best interest of the City, who complies with all the provisions of the invitation to bid. The City reserves the right to reject any or all bids or to waive any non-conformity in bids received whenever such rejection or waiver is in the best interests of the City. The City also reserves the right to reject the bid of a bidder who has previously failed to satisfactorily perform a contract, has not completed contracts on time, or who investigation shows is not in a position to perform the contract.
In determining responsibility, the following qualifications will be considered by the City:
(a) The ability, capacity, and skill of the bidder to perform the contract or provide the service required;
(b) Whether the bidder can perform the contract or provide service promptly, or within the time specified, without delay or interference;
(c) The character, integrity, reputation, judgment, experience, and efficiency of the bidder;
(d) The quality of performance of previous contracts or services;
(e) The previous and existing compliance by the bidder with laws and ordinances relating to the contract or service;
(f) The sufficiency of the financial resources and ability of the bidder to perform the contract or provide the service;
(g) The quality, availability, and adaptability of the supplies or contractual services to the particular use required;
(h) The ability of the bidder to provide future maintenance and service for the use of the subject of the contract;
(i) Bidder's record of experience in construction improvements of the size and type required in the bid specifications;
(j) Lowest bids received including discounts for cash payments.
The City will accept in writing one of the proposals, within ninety (90) days from the date of opening of bids, or the time specified within the specifications, unless the lowest responsible bidder extends the time of acceptance to the City. Notice of Award will be posted on OpenGov, our e-bidding site, for all bidders within the time for acceptance specified in the Invitation to Bid.
Unless otherwise specified by the City, the City reserves the right to make an award on all items, or on any of the items according to the best interests of the City. Bidder may restrict his bid to consideration in the aggregate by so stating but must name a unit price on each item bid upon. The City reserves the right to accept or reject any bid in which the bidder names a total price for all the articles without quoting a price on each and every item.
INTENT OF SPECIFICATIONS
The bid will establish service rates and material rates/material markup percentage/material discount percentage that are all inclusive (i.e. no additional fuel surcharges, shipping fees, etc.). Estimated quantities are for bid purposes only. Total quantities shall be determined by the City of Naperville Department of Electric Utility based upon actual need.
The City reserves the right to change the scope of duties, adjust service levels, hire other additional contractors, do the work with City staff or take other measures consistent with City policies, procedures, and/or act in capacities in the best interest of the City. This contract shall be subject to the provisions of all pertinent ordinances of the City of Naperville Electric Utility, which ordinances are hereby made a part hereof with the same force and effect as if specifically set out herein.
“Contractor” means the company, employees, or agents proposing to provide winter operation services to the City of Naperville. “City” shall mean the City of Naperville, the Naperville Electric Utility (Utility), its employees, or other authorized City personnel.
Distribution Equipment refers generally to green colored equipment that is within public right-of-ways or easements where internal components are energized at 12,470V and below.
Substation Equipment refers generally to equipment within fenced in substation yards, not accessible to the public, and operates at voltages up to 138,000V.
This initial term contract shall cover the period from date of award through December 31, 2027 with consideration for three additional one-year options. However, it must be clearly understood that the City Council approves funding and budgets for a one (1) year period, beginning on January 1, and that the initial contract places NO obligation on the City to appropriate funding beyond the initial first year. Any contract extensions are contingent upon available funding, service arrangement, cost factors, and the Contractor's performance under the contract. The City may elect to seek additional services from other vendors or terminate this contract with a thirty-day written notice.
If any of the provisions of this contract are violated by the Contractor, the City may serve written notice upon the Contractor and the Surety of its intention to terminate such contract. Unless the Contractor rectifies such violations within ten (10) days after the serving of such notice upon the Contractor from the City, the contract shall cease and terminate. In the event of any such termination, the Owner shall immediately serve notice thereof upon the Surety and the Contractor. The City would then have the option to take over the work and prosecute the same to completion at the expense of the Contractor.
The City of Naperville Electric Utility is seeking a Contractor to perform welding, patching, prepping, and painting of electrical equipment consisting of substation transformers, distribution transformers, pad mounted distribution switches, fuse cans, plug cans, and other electrical devices within the City of Naperville. On distribution equipment, patching is allowable up to 144 square inches. Welding is allowable up to 48 linear inches, or; for up to $1,000 for a single phase transformer/single phase plug or fuse can/three phase plug or fuse can, or $3,000 for a pad mounted switchgear.. For Substation equipment, any patching must be preapproved, and there shall be no welding on any substation device. Work is preferred to take place in the field while in operation for distribution equipment. Substation items must be taken out of service for safety. Stock items may be repaired/painted at the City’s address, 1392 Aurora Avenue Naperville IL 60540, or if close enough, at the Contractor’s premises.
The Contractor's schedule of work shall be coordinated with the City. This not only includes the sequence of projects but also the number of crews working as reasonably required for the City to meet its commitments. The Contractor shall have the capability of running multiple crews when requested by the City. Projects should begin within 5 days after notification from the City and proceed with all required work in a continuous and workmanlike manner to full completion of the project and to the satisfaction of the City. The Contractor must staff crews accordingly to meet any City assigned deadlines as required.
After the City has notified the Contractor to begin work on a project(s) or to add additional crews, the Contractor shall arrange for qualified personnel, equipment and tools and schedule the work with the City as required. As dictated by the City, the Contractor shall notify the City, in writing, two (2) working days before starting work on a project(s). In case of a temporary suspension of work, he shall give a similar notice before resuming work.
For substation equipment that will be out of service for the painting, time will be of the essence and Contractor shall deploy appropriate resources and maintain work hours to support returning the equipment to service as soon as practical. Unnecessary delays on substation equipment outages shall be grounds for immediate termination of the Contract.
The Contractor must have a local phone number or toll-free number for the City to communicate with the Contractor. All crews and supervisors must utilize cellular communication for means of communicating with City personnel.
Note: The bid price per unit shall include all fees associated with that corresponding project except for Patching and Welding which are paid out as options.
See Technical Standards and Materials Specifications for details
The City shall always have access to the work wherever it is in preparation or progress and the Contractor shall provide proper facilities for such access and for inspections.
The Contractor shall:
The Contractor shall be required to show to the Utility that they have the necessary facilities, ability, and resources to provide the high-quality equipment painting services specified herein and have a minimum of 10 years servicing municipal, institutional, or commercial accounts. The City reserves the right to reject any proposal if the evidence submitted by, or investigation of, the Contractor fails to satisfy to the City employees that the Contractor is properly qualified to carry out the obligations of the contract and to complete the work described herein.
It shall be expressly understood that the Contractor shall make no claims for extra work unless such work has been ordered in writing to or by the City. Additional equipment, including providing necessary safety measures to provide for the safety of the general public as well as employees for the Contractor, shall be included in this contract as part of the work units bid under this contract, and not to be paid as additions to the work units.
Where required, the Contractor is responsible for obtaining all necessary licenses and permits required to conduct business in the City of Naperville. These licenses are available through the City Clerk's Office.
The Contractor will be responsible for all permits other than the Right of Way (ROW) permits issued from the Department of Transportation, Engineering, and Development (TED). Some of these may consist of but not limited to: storage of equipment, parking permits, IEPA permits, IDOT permits, and railroad permits.
The Contractor will procure and pay for all licenses and bonds necessary for the prosecution of the work, and/or required by appropriate jurisdictions. The Contractor shall give all notices, pay all fees and comply with all Federal, State, and Municipal laws, ordinances, rules and regulations, building and construction codes bearing on the conduct of the work.
The Contractor shall be required to provide a minimum of four favorable current or previous commercial customer references for work similar in size and scope to the work outlined in the specifications. The Contractor shall include the names, addresses, contact person(s), phone numbers, email addresses, type of service provided and current length in time serving each referenced customer. List references for any municipal work that your firm has done.
All work under this contract shall be conducted during normal business hours as determined by the City. The City’s normal business hours are 7:00 a.m. to 3:30 p.m. Monday through Friday. There shall be no work performed on City approved holidays, unless instructed otherwise. There may be some projects where the start and stop times may not coincide with the normal times, but the Contractor will be given ample amount of time to coordinate such work.
The cost of providing necessary safety measures to provide for the safety of the public as well as employees for the Contractor shall be included in this contract as part of the work units bid under this contract, and not to be paid as additions to the work units.
Fire Resistant Clothing is required for all Contractor employees who enter substations or may perform work on or near exposed electrical parts.
Access to the Substation yards and Substation buildings by NEU Engineering, Non-NEU City Employees, or Contractors, not actively working on live equipment, requires a minimum:
The Contractor shall be bound by all of the City’s rules and regulations governing the Contractor’s work, such as, but not limited to, Federal OSHA and Federal and State EPA regulations.
The Contractor shall be responsible for furnishing, installing, maintenance, replacement, relocation, and removal of all traffic control devices used for the purpose of regulating, warning, or directing traffic as necessary to safely and legally perform the work under this contract. The traffic control and protection shall be in accordance with the Illinois Manual on Uniform Traffic Control Devices for Streets and Highways as well as the City of Naperville’s Department of Transportation Traffic Standards.
Where required by OSHA, IDOT, or the Naperville Department of Public Works (NDPW), the Contractor shall provide traffic control and protection in accordance with the Illinois Department of Transportation’s “Standard Specifications for Traffic Control Items” and the “Illinois Manual for Uniform Traffic Control Devices for Streets and Highways”. Any required lane closures will not begin prior to 9:00am and extend past 3:00pm.
The Contractor shall complete any special reports which might be required by the City, such as an accident report if the occasion arises.
The Contractor shall employ only competent and skilled personnel. All employees of the Contractor must exhibit an acceptable appearance and shall carry some form of identification when on duty. The Utility shall have the authority to order the removal from the jobsite any of the Contractor’s employees who refuse to obey any instructions or who is deemed incompetent, abusive, threatening or disorderly in his conduct, or is performing work in an unsafe manner. Any such person shall not again be used on this contract.
All Contractor vehicles must be identified with company name, phone number, and identification stating they are a Contractor for the City of Naperville Electric Utility.
The Contractor shall not be allowed to subcontract service under this agreement without the written consent of the Utility. If approved, the subcontractor(s) shall be bound by the conditions of the agreement between the Utility and the Contractor and shall perform his/her work in accordance with all terms of this agreement and specifications.
The Contractor shall exercise all necessary caution to protect pedestrian traffic and to protect all public and private property from injury or damage caused by the Contractor’s operations. Any practice deemed hazardous by designated or other qualified Utility staff shall be immediately halted upon verbal or written notification. The Contractor shall comply with all OSHA, NIOSH, and other applicable federal, state, and local regulations, codes, and/or ordinances.
The Contractor will be responsible for all damage to property, public or private, that may be caused by his operations in the performance of this contract, and the Contractor shall defend any suit or legal action that may be brought against himself or the City on account of damage inflicted by the Contractor’s operations and shall pay any judgments awarded to cover such damage.
The Contractor shall maintain the cleanliness of the City streets and all paved approaches to the work site in accordance with Section No. 9-1A-16, Article 1.1.1 of the City’s Municipal Code and shall remove all mud or spoils from said streets upon direction of City. This shall include but not be limited to pressure washing walkways and roadways to safeguard pedestrians and vehicle traffic.
It is strongly recommended that the Contractor electronically document (video/camera) the construction area prior to any work commencing. This may save time and efforts in the event a damage claim is filed against the Contractor.
If a roadway or other public or private improvement is damaged during work under this contract; or if a roadway or other public or private improvement must be disturbed; the Contractor agrees to assume full responsibility for all costs associated with the restoration of the damaged property. The costs under this section include, but are not limited to, the costs of permits, fines, restoration, etc.
The Contractor shall have complete responsibility for any costs associated with damage, which may be caused to the facilities of the City or any other utility, both public and private, during the execution of the work. The Contractor agrees to hold the City harmless of any costs which may be incurred as a result of any damage resulting from the Contractor’s work under this contract.
Any delay the City may experience due to the Contractor’s negligence will result in the City charging the Contractor for all associated downtime. This downtime will be calculated on labor, employee benefits, and vehicles involved.
The City may withhold, in addition to retained percentages from payment to the Contractor, such an amount or amounts as may be necessary to cover:
At all times, the City reserves the right to use another contractor, not party to this contract, if the City
determines that the costs quoted for changes or addition to the project under this contract are unreasonable.
It shall be expressly understood and hereby agreed to by the Contractor that no claims for extra work will be recognized unless previously expressed in writing to the City in advance of billing. In the final invoice, the Contractor shall provide narrative statements indicating what each separate line item for additional work was for.
If the proposal for the work under this contract is on a unit price basis, the actual number of units of each item of work to be constructed may be more or less than the corresponding number given in the proposal sheet or plan. No variation will be made in the contract unit prices on that account. Only the actual units of work shall be considered when determining unit quantities from the project plans.
Neither the final payment nor any provision in the contract documents shall relieve the Contractor of the responsibility for negligence of faulty materials or workmanship within the extent and period provided by law.
If the Contractor should neglect to execute the work properly or fail to perform any provision of this contract, the City, may without prejudice to any other remedy he may have, make good such deficiencies, deduct the cost thereof from the payment due the Contractor and require immediate removal of any unsatisfactory employee as determined by the City. The cost shall be determined by actual expenses plus overhead.
The Contractor shall guarantee the work to be free from defects of any nature, and any visible rust, for a period of four (4) years from and after the final acceptance and payment for the work by the City. The Contractor shall make all needed repairs and/or reconditioning during this four-year period which, in the judgment of the City, may be necessary to ensure the delivery of the work to the City at the expiration of the guarantee period in first class condition and in full conformity with the plans and specifications thereof. The time that the work is in need of repair and/or reconditioning to attain full conformity with the plans and specifications shall not be included in the four-year guarantees included in this contract but shall be in addition thereto.
The Contractor shall prepare and submit itemized invoices no more than seven (7) days after the invoiced work is completed. The invoices are to be submitted to the Electric Utility via e-mail to
Electric Utility Supervisor, Laura Hanna, at hannal@naperville.il.us .
The Electric Utility will not process incorrect invoices for payment. In the event of an incorrect invoice, the Electric Utility personnel will inform the vendor of the billing error and the vendor must remit one correct invoice for payment to the Electric Utility. Any downtime the Contractor may experience with projects will not be compensated in any form from the City.
Invoices shall contain; but are not limited to the following information:
Technical Standards and Material Specifications
In the event of a tie, the City will give preference according to the Veterans Preference Act; Illinois Revised Statutes, Chapter 126-1/2, Section 23, Effective July 1, 1935 as amended September 6, 1990; In the employment and appointment to fill positions in the construction, addition to, or alteration of all public works undertaken or contracted for by the State, or by any political subdivision there, preference shall be given to persons who have been members of the armed forces of the United States or who, while citizens of the United States, were members of the armed forces of allies of the United States in time of hostilities with a foreign country, and have served under one or more of the following conditions:
(1) The veteran served a total of at least six months, or
(2) The veteran served for the duration of hostilities regardless of the length of engagement, or
(3) The veteran served in the theater of operations but was discharged on the basis of hardship, or
(4) The veteran was released from active duty because of a service connected disability and was honorably discharged. But such preference shall be given only to those persons who are found to possess the business capacity necessary for the proper discharge of the duties of such employment. No political subdivision or person contracting for such public works is required to give preference to veterans, not residents of such districts, over residents thereof who are not veterans.
When noted in the specifications, the City reserves the right to require the successful bidder to supply a Performance Bond and a Labor and Materials Bond within ten (10) calendar days of acceptance of the bidder's proposal by the City. The bonds, unless otherwise specified by the Procurement Manager, shall be 100% of the total contract price.
In the event that the bidder fails to furnish the above mentioned bonds within ten (10) calendar days after acceptance of bid by the City, then the bid deposit of the bidder shall be retained by the City as liquidated damages, it being now agreed that said sum is a fair estimate of the amount of damages that said City will sustain due to the bidder's failure to furnish said bonds.
The following are City specifications.
When a formal, numbered specification is referred to in this invitation, no deviation from that specification will be permitted.
Any reference in the City's specifications to a manufacturer's catalog number is descriptive, not restrictive, indicating articles that are satisfactory. Bids on other makes and catalogs will be considered, provided the bidder clearly states on the face of his proposal exactly what he proposes to furnish; or forwards with his bid, a cut, illustration, or other descriptive matter which will clearly indicate the character of the article covered by his bid.
Where the bidder identifies an item by manufacturer's name, trade name, catalog number, or reference, the bidder shall furnish the item so identified and shall not propose to furnish an "equal" unless the proposed "equal" is definitely indicated within the bid.
The Procurement Manager hereby reserves the right to approve as an equal, or to reject as not being equal, any article the bidder proposed to furnish which contains major or minor variations from specifications requirements, but which may comply substantially therewith.
If no particular brand, model, or make is specified, and if no data are required to be submitted with the bid, the specifications may require the bidder to submit working drawings or detailed descriptive data sufficient for the City to determine if each requirement of the specifications is being complied with prior to manufacture or shipment.
The following are City price specifications.
Bid prices, unless otherwise specified in the specifications, must be net, including transportation and handling charges fully prepaid by the contractor to delivery point. All prices are subject to Net 30 on commodities, rentals and services unless otherwise specified. Term #24 does not include construction contracts.
Prices must be a firm monetary figure for the cost of the commodity, service, or project. In the event the City invites bids for the purchase of any item or real property, the City shall not accept a bid which is based upon any other bid, contract, or reference to any other document or numbers not included in the bidder’s bid documents.
Sales to the City of Naperville are exempt from state and local retailers' occupation tax, state and local service occupational tax, use tax, and service use tax pursuant to Rule No. 40 of the Illinois Retailers Occupation Tax Rules issued April 15, 1965. Our tax exemption number is E9997-4398-07.
When an error is made in extending total prices, the unit bid price will govern.
The following are City quantity specifications.
Where quantities are specifically stated, acceptance will bind the City to order and pay for, at contract prices, all such supplies or services delivered that meet the specifications and conditions of the contract.
The following are City delivery provisions.
Orders against contracts will be placed with the Contractor on a Purchase Order executed and released by the Procurement Manager. Telephonic orders placed directly with the Contractor by the ordering department may be authorized by the Procurement Manager only after execution of an Open End or Blanket Purchase Order.
The successful bidder shall be responsible for the materials or supplies covered by this contract until they are delivered at the designated point. Rejected materials or supplies must be removed by and at the expense of the contractor promptly after notification or rejection.
Failures of a Contractor to deliver within the time specified, or within a reasonable time as interpreted by the Procurement Manager, or failure to make replacement of rejected articles when so requested, immediately or as directed by the Procurement Manager, shall constitute authority for the Procurement Manager to purchase in the open market articles of comparable grade to replace the articles rejected or not delivered. On all such purchases, either: (1) the Contractor shall reimburse the City, within a reasonable time specified by the Procurement Manager, for any expense incurred in excess of contract prices; or (2) the City may deduct such amount from monies owed the defaulting Contractor. Such purchases shall be deducted from contract quantities. Should public necessity demand it, the City reserves the right to use or consume articles delivered which are substandard in quality, subject to an adjustment in price to be determined by the Procurement Manager.
Unless otherwise specified, goods shall be delivered in commercial packages in standard commercial containers, so constructed as to insure acceptance by common or other carrier for safe transportation, at the lowest rate, to the point of delivery. Containers become the property of the City unless otherwise specified by bidder in his bid.
Inspections and acceptance of materials or supplies will be made after delivery. Final inspection shall be conclusive except as regards latent defects, fraud, or such gross mistakes as to amount to fraud. Final inspection and acceptance or rejection of the materials or supplies will be made as promptly as practicable. All delivered materials shall be accepted subject to inspection and physical count.
All shipments or deliveries shall be accompanied by packing slips or delivery tickets and shall contain the following information for each item delivered:
Purchase Order Number
Quantity Ordered
Name of the Article
Stock Number
Quantity Shipped
Name of the Contractor
Quantity Back Ordered
The City of Naperville’s payment terms are net 30. The payment date will be calculated based on the invoice receipt date or delivery date, whichever is later. All payments shall be made with electronic payment transfer.
Payment:
All invoices shall be addressed to Accounts Payable, City of Naperville, P.O. Box 3020, Naperville, Illinois, 60566-7020, as indicated on the front of this purchase order and must include vendor’s name and phone number, and clearly list quantities, item descriptions and units of measure.
The following are the City financial responsibility provisions.
Contractor agrees to:
(a) Save the City, its agents, and employees harmless from liability of any nature or kind for the use of any copyrighted or uncopyrighted composition, secret process, patented or unpatented invention, article, or appliance furnished or used in the performance of the contract which the Contractor is not the patentee, assignee, licensee, or owner; and
(b) Protect the City against latent defects in materials or workmanship and to repair or replace any articles damaged or marred in transit or during delivery; and
(c) Pay for all permits, licenses, and fees and give all notices and to comply with all laws, ordinances, and rules of the City and the State of Illinois.
Unless otherwise specified, the Contractor shall unconditionally guarantee the materials and workmanship on all equipment furnished by him FOR A PERIOD OF ONE YEAR from date of delivery and installation if required unless otherwise specified in the specifications. If within the guarantee period, any defects or signs of deterioration are noted which, in the opinion of the City, are due to faulty design and installation, workmanship, or materials, the City shall notify the Contractor. At the Contractor's expense, the Contractor shall repair or adjust the equipment or parts to correct the condition or replace the part or entire unit to the complete satisfaction of the City.
At the Contractor's expense, the Contractor shall procure and maintain in effect throughout the duration of this contract, insurance against claims for injuries to persons or damages to property which may arise from or in connection with the performance of the work hereunder by the Contractor, his agents, representatives, employees or subcontractors.
The Contractor must furnish Certificates of Insurance to the City before staff recommends award of the contract to City Council. If requested, the awardee of this bid will give the City a copy of the insurance policies. The policies must be delivered to the City within two weeks of the request. All insurance policies shall be written with insurance companies licensed to do business in the State of Illinois and having a rating of not less than A: VII according to the A.M. Best Company. Should any of the insurance policies be canceled before the expiration date, the issuing company will mail 30 days written notice to the City. The Contractor shall require and verify that all subcontractors maintain insurance meeting all of the requirements stated herein.
Any deductibles or self-insured retentions must be declared to and approved by the City. At the option of the City, either the insurer shall reduce or eliminate such deductibles or self-insured retentions as respects the City, its officers, officials, employees and volunteers; or the Contractor shall provide a financial guarantee satisfactory to the City guaranteeing payment of losses and related investigations, claim administration and defense expenses.
The limits of liability for the insurance required shall provide coverage for not less than the following amounts, or greater where required by law. If the Contractor maintains higher limits than the minimums shown below, the City shall be entitled to coverage for higher limits maintained by the contractor.
(A) Commercial General Liability:
Coverage shall be at least as broad as Insurance Services Office Commercial General Liability coverage (Occurrence Form CG 00 01) and include Premise/Operations, Products/Completed Operations, Independent Contractors, Contractual and Personal Injury/Advertising Injury.
Limits:
General Aggregate $2,000,000.00
Products/Completed Operations $2,000,000.00
Each Occurrence $2,000,000.00
Personal Injury $2,000,000.00
(B) Automobile Liability:
Coverage shall be at least as broad as Insurance Services Office Form CA 00 01 to include all Owned, Hired, Non-owned vehicles.
Limits:
Combined Single Limit Per Accident $2,000,000
(C) Workers’ Compensation:
Coverage shall be as required by the State of Illinois, with Statutory Limits, and Employers’ Liability insurance with a limit of no less than $1,000,000 per accident for bodily injury or disease.
(D) Employers’ Liability
Limits:
Each Accident $1,000,000
Each Employee Bodily Injury by Disease $1,000,000
Policy Limit Bodily Injury by Disease $1,000,000
(E) Other Insurance Provisions
The Commercial General Liability and Automobile Liability policies are to contain, or be endorsed to contain, the following provisions:
1. The City, its officers, officials, employees and volunteers are to be covered as insured’s with respect to liability arising out of automobiles owned, leased, hired or borrowed by or on behalf of the Contractor; and with respect to liability arising out of work or operations performed by or on behalf of the Contractor including materials, parts or equipment furnished in connection with such work or operations. General Liability coverage shall be provided in the form of an Additional Insured endorsement to the Contractor’s insurance policy, or as a separate owner’s policy.
2. For any claims related to this project, the Contactor’s insurance coverage shall be primary insurance as respects the City, its officers, officials, employees and volunteers. Any insurance or self-insurance maintained by the City, its officers, officials, employees or volunteers shall be excess of the Contractor’s insurance and shall not contribute with it.
The Workers’ Compensation policy shall be endorsed with a waiver of subrogation in favor of the City for all work performed by the Contractor, its employees, agents and subcontractors.
The Contractor understands that the acceptance of Certificates of Insurance, policies and any other documents by the City in no way releases the contractor from the requirements set forth herein.
The Contractor shall defend, indemnify, and hold harmless the City and its officers, agents and employees, from any and all liability, losses or damages as a result of claims, demands, suits, actions, or proceedings of any kind of nature,, including but not limited to costs and fees, including reasonable attorney’s fees, resulting from any negligent or willful act or omission on the part of the Contractor or Contractor’s subcontractors, subconsultants, or sub-vendors, or their respective employees, agents and representatives, during the performance of this Agreement, including without limitation, failure to comply with all applicable federal, state, and local laws, rules, ordinances, regulations, orders, federal circulars and all license and permit requirements. Such defense, indemnification, and hold harmless provisions shall not be limited by reason of any insurance coverage provided for herein. Nothing contained herein shall be construed as prohibiting the City, or its officers, agents, or employees, from defending through the selection and use of their own agents, attorneys, and experts, any claims, actions or suits brought against them in which case the Contractor shall be liable for the reasonable cost, fees, and expenses incurred in the defense of any such claims, actions, or suits. Nothing herein shall be construed as a limitation or waiver of defenses available to the City and employees and agents, including but not limited to the Illinois Local Government and Governmental Employees Tort Immunity Act, 745 ILCS 10/1-102 et seq. The provisions of this paragraph shall survive completion, expiration or termination of this Agreement.
The Contractor shall, to the maximum extent permitted by law, indemnify, defend, and hold harmless the City, its officers, employees, agents, and attorneys from and against any and all liability, including without limitation, costs of response, removal, remediation, investigation, property damage, personal injury, damage to natural resources, health assessments, health settlements, attorneys' fees, and other related transaction costs arising under the Comprehensive Environmental Response, Compensation, and Liability Act (CERCLA) of 1980, 42 U.S.C.A. Sec. 9601, et seq., as amended, and all other applicable statutes, regulations, ordinances, and under common law for any release or threatened release of the waste material collected by the Contractor, both before and after its disposal.
Assignment of this contract or any part thereof, or any funds to be received there under by the Contractor shall be subject to the approval of the City of Naperville.
Contracts will remain in force for full periods and until all articles ordered before date of termination shall have been satisfactorily delivered and accepted and thereafter until all requirements and conditions shall have been met, unless:
The contract may be canceled or annulled by the City Council in whole or in part by written notice of default to the Contractor upon non-performance or violation of contract terms. Upon receipt of such notice, the Contractor shall have fourteen (14) days with in which to cure any default or violation. If the default or violation is not cured with in the specified time an award may be made to the next lowest Bidder, or articles specified may be purchased on the open market. In either event, the defaulting Contractor (or his surety) shall be liable to the City for costs incurred by the City in excess of the defaulted contract prices. However, the Contractor shall continue the performance of this contract to the extent not terminated under the provisions of this clause.
It is a federal law that chemical manufacturers and importers must develop an MSDS for each hazardous chemical they produce or import and must provide the MSDS automatically at the time of the initial shipment of a hazardous chemical to a downstream distributor or user, or anytime the chemical makeup of the product is changed. Distributors must also ensure that downstream employers are similarly provided an MSDS.
Vendors who are awarded this contract, and if the above paragraph applies to this bid, must submit Material Data Sheets which include information regarding the specific chemical identity of the hazardous chemical(s) involved and the common names. In addition, information must be provided on the physical and chemical characteristics of the hazardous chemical; known acute and chronic health effects and related health information; exposure limits; whether the chemical is considered to be a carcinogen by NTP, IARC, or OSHA; precautionary measures; emergency and first-aid procedures; and the identification of the organization responsible for preparing the sheet.
The Contractor and Contractor’s employees, agents, subconsultants and subcontractors shall comply with all applicable federal, state and local laws, rules, ordinances, regulations, orders, federal circulars and license and permit requirement in the performance of any Contract pursuant to this bid, including, without limitation and to the extent applicable, the Illinois Prevailing Wage Act, the federal Davis-Bacon Act, and the Employment of Illinois Workers on Public Works Act. The Contractor shall be in compliance with applicable tax requirements and shall be current in payment of such taxes.
This contract shall be governed by and construed according to the laws of the State of Illinois except that sections 2 through 8 of the Local Government Prompt Payment Act (50 ILCS 505/2-8) shall not be applicable. Venue for any action related to this agreement shall be in the Circuit Court for the 18th Judicial Circuit, DuPage County, Illinois.
If this contract calls for the construction of a “public work”, within the meaning of the Illinois Prevailing Wage Act, 820 ILCS 130/.01et seq. (“the Act”), the Act requires contractors and subcontractors to pay laborers, workers and mechanics performing services on public works projects no less than the “prevailing rate of wages” (hourly cash wages plus fringe benefits) in the county where the work is performed. For information regarding current prevailing wage rates, please refer to the Illinois Department of Labor’s website at:
https://www2.illinois.gov/idol/laws-rules/conmed/pages/prevailing-wage-rates.aspx. All contractors and subcontractors rendering services under this contract must comply with all requirements of the Act, including but not limited to, all wage, notice and record keeping duties.
Pursuant to PA 100-1177 and in accordance with 820 ILCS 130/5.1, Contractors shall submit to the Illinois Department of Labor (IDOL) all certified payroll records for prevailing wage work performed by contractor employees or subcontractors. IDOL is charged with developing and maintaining an online portal for prevailing wage construction contractors to file their certified payrolls. The portal may be accessed by visiting https://www2.illinois.gov/idol/Laws-Rules/CONMED/Pages/CertifiedTranscriptOfPayroll.aspx.
Every contractor on a public works project or improvement or hazardous waste clean-up and on-site disposal project in this State may place on such work no more than 3, or 6 in the case of a hazardous waste clean-up and on-site disposal project, of his regularly employed non-resident executive and technical experts, even though they do not qualify as Illinois laborers as defined in Section 1 of Article 2 of this Act.
Whenever a period of time is provided for in this Agreement for either the CITY or Contractor to do or perform any act or obligation, neither party shall be liable for any delays or inability to perform due to causes beyond the control of said party such as war, riot, strike or lockout by or against either party’s own employees or suppliers, unavoidable casualty or damage to personnel, materials or equipment, fire, flood, storm, earthquake, tornado or any act of God; provided, however, that said time period shall be extended for only the actual amount of time said party is so delayed. Except as to a strike or lockout by or against either party’s own employees or suppliers, an act or omission shall not be deemed to be “beyond Contractor’s control” if committed, omitted or caused by Contractor, Contractor’s employees, officers or agents or a subsidiary, affiliate or parent of Contractor or by any corporation or other business entity that holds a controlling interest in Contractor, whether held directly or indirectly.
The order of precedence of the component contract parts shall be as follows:
1. Addenda if any.
2. Project Specific Instructions to Bidders.
3. Project Specific Supplementary Conditions to Project Specific General Conditions.
4. Project Specific General Conditions.
5. City of Naperville General Terms and Conditions and Instruction to Bidders.
6. Special Conditions, Detailed Specifications and Special Provisions.
7. Plans or City drawings.
8. Standard Specifications of the City, State, or Federal Government.
9. Performance Bond, if required.
The foregoing order of precedence shall govern the interpretation of the contract in all cases of conflict or inconsistency therein, except as may be otherwise expressly provided by the City.
In addition, in the case of a conflict between any term or provision contained in the contract documents which cannot be resolved by the order of precedence set forth above, the term or condition that is more stringent and/or specific shall govern and apply.
The following is the City's right to audit clause.
The Contractor shall cooperate with the City and provide the City, when requested, with access to data, information and documentation pertaining to the work. City requests for information may be based on requests from federal or state regulatory agencies, other governmental agencies, courts of law, consultants hired by the City or other parties, which in the City’s opinion, require the information.
Data, information and documentation will include, but not be limited to, original estimate files, change order estimate files and detailed worksheets; subcontract and supplier proposals for both successful and unsuccessful bidders; all project related correspondence; subcontractor and supplier change order files (including detailed documentation covering negotiated settlements); back-charge logs and supporting documentation; any records detailing cash, trade, or volume discounts earned; insurance proceeds, rebates, or dividends received; and any other supporting evidence necessary to substantiate charges related to the contract (both direct and indirect costs, including overhead allocations as they may apply to costs associated with the contract).
The Contractor will provide the City with copies of all requested records in a computer-readable format (if available) as well as hard copy.
The Contractor shall retain and preserve all information relating to the work for a period of at least four (4) years from the date of the completion of the work.
The City will have the right to audit any records necessary to permit evaluation and verification of contractor compliance with contract requirements throughout the term of the contract and for a period of four years after final payment, or longer if required by law.
The City will have the right to interview any of the contractor’s current and former employees, as related to this contract, during the audit.
The Contractor will provide the City with adequate and appropriate work space, with access to photocopy machines, during the audit.
The Contractor will include in its subcontracts a provision granting the City the right of audit provisions against subcontractors as contained in this article.
This contract is contingent on the receipt of funding in future years. The terms of this contract and any Purchase Order issued for multiple years under the Contract are contingent upon sufficient appropriations being approved by the City Council. Notwithstanding any language to the contrary in the solicitation, purchase order, or any other Contract document, the City may terminate its obligations if sufficient appropriations are not approved by the City Council. The City’s decision as to whether sufficient appropriations are available is final and binding on all parties.
The Contractor shall be required to provide a minimum of four favorable current or previous commercial customer references for work similar in size and scope to the work outlined in the specifications.
Name of Client or Municipality:
Address:
Contact Person:
Title:
Phone Number:
Email Address:
Size of the facility:
Contract Dates:
Contract Amount:
Name of Client or Municipality:
Address:
Contact Person:
Title:
Phone Number:
Email Address:
Size of the facility:
Contract Dates:
Contract Amount:
Name of Client or Municipality:
Address:
Contact Person:
Title:
Phone Number:
Email Address:
Size of the facility:
Contract Dates:
Contract Amount:
Name of Client or Municipality:
Address:
Contact Person:
Title:
Phone Number:
Email Address:
Size of the facility:
Contract Dates:
Contract Amount:
Please download the below documents, complete, and upload.
Please upload the Bid Deposit of 10%
Please download the below documents, complete, and upload.
Please download the below documents, complete, and upload.
Please upload proper documentation.
Please upload any additional information or documentation that you believe is relevant to this solicitation.
Section preferred
SLED stands for State, Local, and Education. These are solicitations issued by state governments, counties, cities, school districts, utilities, and higher education institutions — as opposed to federal agencies.
SamSearch Platform
AI-powered intelligence for the right opportunities, the right leads, and the right time.