Active SLED Opportunity · TEXAS · HOUSTON-GALVESTON AREA COUNCIL
AI Summary
H-GAC seeks proposals to upgrade Kentico Xperience and migrate H-GAC.com and WrkSolutions.com websites. The project includes cloud hosting evaluation, migration planning, and integration validation. Proposals are due by June 11, 2026, with evaluation based on methodology, technical expertise, experience, team qualifications, risk management, and cost.
H-GAC is soliciting proposals to successfully complete an upgrade to Xperience by Kentico and migrate the H-GAC.com and WrkSolutions.com live sites into the upgraded Kentico implementation.
The Houston-Galveston Area Council (H-GAC) is the region-wide voluntary association of 133 local governments and local elected officials in the 13-county Gulf Coast Planning region of Texas. Local elected officials organized H-GAC in 1966 after authorization by State enabling legislation. Its service area is 12,500 square miles and includes more than 7-million residents. H-GAC is governed by a 36-member Board of Directors composed of local elected officials, who serve on the governing bodies of member local governments. All H-GAC programs are carried out under the policy direction of its Board of Directors. H-GAC’s mission is to serve as the instrument of local government cooperation, promoting the region’s orderly development and the safety and welfare of its residents. H-GAC is the regional organization through which local governments consider issues and cooperate in solving area-wide problems. Agency programs emphasize local government concerns, such as transportation, air and water quality, criminal justice, demographic analysis, mapping programs, and intergovernmental purchasing. H-GAC also serves its citizens through workforce development programs, services to the aging and elderly, and small business finance programs.
Price/Cost is reasonable and a detailed cost breakdown is provided.
Potential proposers invited to Phase 2 will be notified of the time and place of oral interviews/demonstrations.
Please complete each section listed below and upload/respond to the questions or provide the information as directed.
Provide a summary of key aspects of the contractor’s qualifications and indicate the Respondent’s commitment to provide the services proposed and certify that all statements and information prepared and submitted in the response to this Solicitation are current, complete, and accurate; and that the proposed solution for the project meets all the requirements of this Solicitation.
Submit details regarding approach to undertaking the tasks listed in this Solicitation. A recommended methodology for performance of each task identified in the scope of work must be included, along with a timeline for completion. Joint submissions must describe how the partners will support each other in ensuring a successful outcome The timeline must illustrate key milestones and anticipate necessary meetings with H-GAC staff.
Submit details regarding experience with Xperience by Kentico architecture and designing cloud hosting solutions (Azure, SaaS models). Describe security, performance, and scalability practices. Provide examples of multi‑environment development workflows and Cloudflare usage.
Provide case studies of similar CMS upgrades or migrations. Submit detailed experience migrating on‑premise platforms to cloud hosting and experience with government or public‑sector projects. Provide three (3) client references for similar services performed; follow the format below for each:
Submit detail outlining the project manager and key staff members and a clear indication as to their involvement in the project. Substitutions for essential personnel involved will not be allowed without H-GAC’s prior approval and resulting delays will be the responsibility of the Contractor. H-GAC retains the right to request the removal of any personnel found, in H-GAC’s opinion, to be unqualified to perform the work. Submit additional information Respondent deems pertinent to demonstrating qualifications and/or experience to perform the services being requested such relevant certifications (Kentico, Azure, cloud architecture, security), memberships in any professional associations, documents, examples, and others.
Please upload resumes here.
Submit a strategy for identifying and mitigating migration risks, testing and rollback procedures, and approach to backup and disaster recovery. Provide a downtime minimization strategy and post‑migration stabilization plan.
The documents/certifications/confirmations below are required for every Solicitation.
Submission must be signed by a duly authorized representative(s) of the respondent, which must be the actual legal entity that will perform the contract if awarded and any total fixed price contained therein will remain firm for a period of one-hundred eighty (180) days following the submission due date and can be further extended by mutual written agreement.
A signature (electronic) constitutes acknowledgement and acceptance of all the Solicitation Terms and Conditions. Respondents, their authorized representative, and their agents are responsible for obtaining, and will be deemed to have, full knowledge of the conditions, requirements, and specifications of this Solicitation at the time a response is submitted to H-GAC. This Solicitation does not commit H-GAC to award a contract, issue a Purchase Order, or pay any costs incurred in the preparation of a submission to this Solicitation. The submission will become part of H-GAC’s official files without any obligation on H-GAC’s behalf. All Submissions will be held confidential from all parties other than H-GAC, and only released in accordance with Public Information Act requirements.
Respondent agrees and understands the above requirements, and by confirming, I certify that I am legally authorized to bind the entity to the Terms and Conditions of the Proposal as submitted. I also agree that any other related documents entered into in connection with this Proposal, which include a digital acknowledgement or electronic signature, are to be treated in all respects as having the same force and effect as original signatures.
Signature of the person authorized to bind Respondent company to any contract/purchase order that may result from this Solicitation and acknowledgement and acceptance of the full Solicitation Terms and Conditions.
Please type (sign) Authorized Signor Name and Title Here:
To ensure a fair and competitive environment, direct communication between H-GAC employees other than the Solicitation Contact or any party able to create an unfair advantage to Respondent or disadvantage to other Respondents with respect to the Solicitation process, or the award of a Contract is strictly prohibited. This restricted period of communication begins on the issue date of the Solicitation and for Respondent(s) not selected for award ends with the conclusion of the protest period identified in the Solicitation document and for Respondents(s) selected for award ends with the Contract execution. This restriction does not apply to communications to other H-GAC employees during a Pre-Proposal/Bid or Response conference or other situations where the Solicitation Contact has expressly authorized direct communications with other staff. A Respondent who intentionally violates this requirement of the Solicitation process or otherwise deliberately or unintentionally benefits from such a violation by another party may have its Submission rejected in accordance with H-GAC Procurement Policy. Respondent(s) will not offer any gratuities, favors, or anything of monetary value to any official or employee of H-GAC (including any and all members of the evaluation committee) for the purposes of influencing consideration of any Submission.
Respondent agrees and understands the above requirement.
Please download the below documents, complete, and upload.
Debarment and Suspension (Executive Orders 12549 and 12689) – A contract award (2 CFR 180.220) must not be made to parties listed on the government-wide exclusions in the System for Award Management (SAM), in accordance with the OMB guidelines at 2 CFR 180 that implement Executive Orders 12549 (3 CFR Part 1966 Comp. p. 189) and 12689 (3 CFR Part 1989 Comp. p. 235), “Debarment and Suspension.” SAM Exclusions contains the names of parties debarred, suspended, or otherwise excluded by agencies, as well as parties declared ineligible under statutory or regulatory authority other than Executive Order 12549. Respondent certifies that neither it nor its principals are presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participation by any federal department or agency or by the State of Texas and at all times during the term of the Contract neither it nor its principals will be debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participation by any federal department or agency or by the State of Texas. Respondent shall immediately provide the written notice to H-GAC if at any time the Respondent learns that this certification was erroneous when submitted or has become erroneous by reason of changed circumstances. H-GAC may rely upon a certification of the Respondent that the Respondent is not debarred, suspended, ineligible, or voluntarily excluded from the covered contract, unless the H-GAC knows the certification is erroneous.
Please download the below documents, complete, and upload.
The undersigned certifies, to the best of his or her knowledge and belief, that:
(1) No Federal appropriated funds have been paid or will be paid, by or on behalf of the undersigned, to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with the awarding of any Federal grant, the making of any Federal loan, the entering into of any cooperative agreement, and the extension, continuation, renewal, amendment or modification of any Federal contract, grant, loan, or cooperative agreement.
(2) If any funds other than Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with this Federal contract, grant, loan, or cooperative agreement, the undersigned shall complete and submit Standard Form- LLL, "Disclosure of Lobbying Activities," in accordance with its instructions.
(3) The undersigned shall require that the language of this certification be included in the award documents of all sub-awards at all tiers (including subcontracts, sub-grants, and contracts under grants, loans, and cooperative agreements) and that all sub- recipients shall certify and disclose accordingly.
This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Submission of this certification is a prerequisite for making or entering into this transaction imposed by section 1352, title 31, United States Code. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure.
Respondent represents and warrants that it shall comply with the applicable provisions of the Drug-Free Workplace Act of 1988 (41 U.S.C. § 701 et seq.) and maintain a drug-free work environment. H-GAC may request a copy of this policy upon contract award.
The grantee certifies that it will provide a drug-free workplace by: (a) Publishing a statement notifying employees that the unlawful manufacture, distribution, dispensing, possession or use of a controlled substance is prohibited in the grantee’s workplace and specifying the actions that will be taken against employees for violation of such prohibition; (b) Establishing a drug-free awareness program to inform employees about— (1) The dangers of drug abuse in the workplace; (2) The grantee’s policy of maintaining a drug-free workplace; (3) Any available drug counseling, rehabilitation and employee assistance programs, and (4) The penalties that may be imposed upon employees for drug abuse violations occurring in the workplace. (c) Making it a requirement that each employee to be engaged in the performance of the grant be given a copy of the statement required by paragraph (a); (d) Notifying the employee in the statement required by paragraph (a) that, as a condition of employment under the grant, the employee will— (1) Abide by the terms of the statement; and (2) Notify the employer of any criminal drug statute conviction for a violation occurring in the workplace no later than five days after each conviction; (e) Notifying the agency within ten days after receiving notice under subparagraph (d)(2) from an employee or otherwise receiving actual notice of such conviction; (f) Taking one of the following actions, within 30 days of receiving notice under subparagraph (d)(2), with respect to any employee who is so convicted— (1) Taking appropriate personnel action against such an employee, up to and including termination; or (2) Requiring such employee to participate satisfactorily in a drug abuse assistance or rehabilitation program approved for such purposes by a Federal, State, or local health, law enforcement, or other appropriate agency; (g) Making a good faith effort to continue to maintain a drug-free workplace through implementation of paragraphs (a), (b), (c), (d), (e) and (f).
Respondent represents and warrants its compliance with all applicable duly enacted state and federal laws governing equal employment opportunities. The equal opportunity clause provided under 41 CFR 60-1.4(b) is hereby incorporated by reference.
Under Section 161.0085 of the Texas Health and Safety Code, Respondent certifies that the individual or business entity named in this Response or contract is not ineligible to receive the specified contract. A business in this state may not require a customer to provide any documentation certifying the customer's COVID-19 vaccination or post-transmission recovery on entry to, to gain access to, or to receive service from the business. A business that fails to comply with this subsection is not eligible to receive a grant or enter into a contract payable with state funds.
No officer, member or employee of the Contractor or Contractors subcontractor, no member of the governing body of the Contractor, and no other public officials of the Contractor who exercise any functions or responsibilities in the review or Contractor approval of this Master Agreement, shall participate in any decision relating to this Master Agreement which affects his or her personal interest, or shall have any personal or pecuniary interest, direct or indirect, in this Master Agreement.
As required by Section 2252.908 of the Texas Government Code. H-GAC will not enter a Contract with Contractor unless (i) the Contractor submits a disclosure of interested parties form to H-GAC at the time the Contractor submits the contract H-GAC, or (ii) the Contractor is exempt from such requirement. The required form and instructions are located at the Texas Ethics Commission website https://www.ethics.state.tx.us/whatsnew/elf_info_form1295.htm. Respondents who are awarded a Contract must submit their Form 1295 with the submission to H-GAC.
Please download the below document, complete, and upload. Download a blank Form here:
No officer, member or employee of the Contractor or Contractors subcontractor, no member of the governing body of the Contractor, and no other public officials of the Contractor who exercise any functions or responsibilities in the review or Contractor approval of this Master Agreement, shall participate in any decision relating to this Master Agreement which affects his or her personal interest, or shall have any personal or pecuniary interest, direct or indirect, in this Master Agreement.
Chapter 176 of the Texas Local Government Code requires contractors contracting or seeking to contract with H-GAC to file a conflict-of-interest questionnaire (CIQ) if they have an employment or other business relationship with an H-GAC officer or an officer's close family member. H-GAC officers include its Board of Directors and Executive Director, who are listed on the H-GAC website. Respondent must complete and file a CIQ with the Texas Ethics Commission if an employment or business relationship with H-GAC officer or an officer's close family member as defined in the law exists. The required questionnaire and instructions are located on the Conflict of Interest page on the Texas Ethics Commission website. https://www.ethics.state.tx.us/forms/conflict/
Please confirm to acknowledge that the form will be filed if applicable.
Respondent represents and warrants that all statements and information prepared and submitted in this response are current, complete, true, and accurate. Submitting a Response with a false statement or material misrepresentations made during the performance of a contract is a material breach of contract and may void the submitted Response and any resulting contract.
Pursuant to Section 2155.004(a) of the Texas Government Code, Respondent certifies that neither Respondent nor any person or entity represented by Respondent has received compensation from H-GAC to participate in the preparation of the specifications or solicitation on which this Response or contract is based. Under Section 2155.004(b) of the Texas Government Code, Respondent certifies that the individual or business entity named in this Response or contract is not ineligible to receive the specified contract and acknowledges that the contract may be terminated and payment withheld if this certification is inaccurate.
Respondent will not collude, in any manner, or engage in any practice, with any other Respondent(s) which may restrict or eliminate competition or otherwise restrain trade. Respondent also represents and warrants that, in accordance with Section 2155.005 of the Texas Government Code, neither Respondent nor the firm, corporation, partnership, or institution represented by Respondent, or anyone acting for such a firm, corporation or institution has (1) violated any provision of the Texas Free Enterprise and Antitrust Act of 1983, Chapter 15 of the Texas Business and Commerce Code, or the federal antitrust laws, or (2) communicated directly or indirectly the contents of this Response to any competitor or any other person engaged in the same line of business as Respondent.
Respondent agrees that it has read, understands, and fully intends to comply with the solicitation terms and conditions, and any additional terms and conditions (as applicable and included as additional sections, attachments or additional documents) of this solicitation as applicable to any subsequent contract or funding agency requirements or agreements. Exceptions to these Terms and Conditions are not permitted and will not be reviewed.
SLED stands for State, Local, and Education. These are solicitations issued by state governments, counties, cities, school districts, utilities, and higher education institutions — as opposed to federal agencies.
SamSearch Platform
AI-powered intelligence for the right opportunities, the right leads, and the right time.