Active SLED Opportunity · CALIFORNIA · CITY OF RANCHO CORDOVA
AI Summary
City of Rancho Cordova seeks bids for the Tributary 2 Fencing Project involving fabrication and installation of wrought iron fencing and gates, removal of existing fencing, and related site work. Estimated cost $600,000. Bids due July 22, 2026. Contractor must hold Class A or C-13 license and comply with federal and state regulations.
The City of Rancho Cordova is seeking competitive bids for Tributary 2 Fencing Project.
Estimated Construction Cost: $600,000
Contractor License Required: Class A General Engineering License or Class C-13 Fencing Contractor License
Bids due before 2:00 pm on Wednesday, July 22, 2026.
| Event | Date | Location |
|---|---|---|
| Bid Opening | 2026-07-22T21:01:00.000Z | https://teams.microsoft.com/meet/28581552670354?p=mgyzhVJCvQdcrTT10D Meeting ID: 285 815 526 703 54 Passcode: kS6q5H8x |
The bidder's attention is directed to the provisions in Section 2, “Bid Requirements and Conditions,” of the Standard Construction Specifications and these special provisions for the requirements and conditions which the bidder must observe in the preparation of and the submission of the bid.
The bidder's bond shall conform to the bond form in the Bid book for the project and shall be properly filled out and executed. The bidder’s bond form included in that book may be used.
In conformance with Public Contract Code Section 7106, a Noncollusion Affidavit is included in the Bid book. Signing the Bid book shall also constitute signature of the Non-Collusion Affidavit.
The Contractor, sub-recipient or subcontractor shall not discriminate on the basis of race, color, national origin, or sex in the performance of this contract. The contractor shall carry out applicable requirements of Title 49 CFR (Code of Federal Regulations), Part 26 in the award and administration of US DOT-assisted contracts. Failure by the Contractor to carry out these requirements is a material breach of this contract, which may result in the termination of this contract or such other remedy, as the recipient deems appropriate. Each subcontract signed by the bidder must include this assurance.
Failure of the bidder to fulfill the requirements of the Special Provisions for submittals required to be furnished after bid opening, including but not limited to escrowed bid documents, where applicable, may subject the bidder to a determination of the bidder's responsibility in the event it is the apparent low bidder on a future public works contracts.
This work consists of preparatory work and operations, including, but not limited to, those necessary for the movement of personnel, equipment, supplies, and incidentals to the site; for the establishment of all offices, buildings, construction yards and other facilities necessary for the work; construction staking of property line; and for all other work and operations which must be performed, or for costs incurred, prior to beginning the work. This item includes the costs of obtaining necessary bonds, insurance, notification hangers, and any other associated fees necessary to perform the work; and includes removal of all construction equipment, personnel, construction related materials, temporary facilities, construction markings/paint, debris, and all other construction related items.
Measurement and Payment:
Mobilization shall be paid for on a LUMP SUM basis. Measurement will be based on the percentage of work completed as determined by the City Engineer. Progress payments shall not exceed 75% until final closeout documents, including record drawing markups, are received and full demobilization, including equipment and material being removed from the site, has occurred. The contract lump sum price paid for Mobilization shall include full compensation for furnishing all labor, materials, tools, equipment and incidentals, and for doing all the work involved in mobilization and demobilization as specified herein, complete and in place, specified in the Standard Specifications, these Special Provisions, and as directed by the City Engineer, and no additional compensation will be allowed. The lump sum bid for Mobilization shall not exceed 10% of the total bid price.
Here are some notes on how to use this template for Federal Grants:
Upload latest 12-G under Attachments
Verify all Caltrans forms in the Bid-Submittal are up to date
Add your DBE goal in the setup questions.
Add the trainee requirements below.
Verify FHWA 1273 has not changed
Delete this section once complete.
Each Bidder shall, at their own expense and prior to submitting a bid, examine the project site(s) and become fully informed regarding all conditions that may affect the cost, progress, or performance of the Work. Other inspections shall be arranged between the hours of 7:30 a.m. and 5:00 p.m. on weekdays only by contacting Dang Bui by email at dbui@cityofranchocordova.gov.
Submission of a bid by the bidder shall constitute acknowledgement that, if awarded the contract, the bidder has relied and is relying on its own examination of (a) the sites of work, (b) access to the sites and (c) all other data and matters requisite to the fulfillment of the work and on its own knowledge of the facilities on and in the vicinity of the sites of the work to be constructed under the contract.
The project site is generally located outside of active traffic areas; however, construction activities may affect access and traffic circulation at 3421 Bradshaw Road and 9738 Lincoln Village Drive. The Contractor shall prepare and submit a Traffic Control Plan to maintain traffic and access at these locations. No work shall commence until the Traffic Control Plan (TCP) has been submitted by the Contractor and reviewed and approved by the City Engineer.
Measurement and Payment:
All costs for maintaining traffic control systems and preparation of a traffic control plan shall be included in the LUMP SUM price. This shall include full compensation for furnishing all labor, materials, tools, equipment and incidentals, and for doing all the work involved in placing, removing, storing, maintaining, moving to new locations, replacing, and disposing of the components of the traffic control systems as shown on the TCP, required to maintain traffic as specified in the State Standard Specifications, in these Special Provisions, and as directed by the City Engineer and no additional compensation shall be allowed therefore.
The work to be done under this contract consists, in general, of furnishing all labor, materials, tools, equipment, incidentals, and for doing all work necessary for fabricating and installing wrought iron fence and foundations, pedestrian and utility gates, removal and disposal of existing fence, as well as other items and details not mentioned above but described in the special provisions or shown on the plans or as designated by the Engineer.
Such other items or details not mentioned above or in the bid quantities that are required by the Plans and/or these Special Provisions, shall be performed, placed, constructed, or installed in accordance with the Standard Construction Specifications or these Special Provisions.
Here are some notes on how to use this template for State Grants:
Delete the federal provisions not required for the State Grants
Remove the FHWA 1273
Verify Caltrans form in the Bid-Submittal are up to date
Delete this section once complete.
The Project Plans and Special Provisions are intended to be explanatory of each other. The work shall be performed and completed according to the true spirit, meaning, and intent of the Plans and Special Provisions.
All work shown on the Plans shall be accurately followed to the scale to which the drawings are made, but figured dimensions are in all cases to be followed where given though they may differ from scaled measurements. Large-scale and / or full-size drawings shall be followed in preference to small-scale drawings. Any discrepancies found in the dimensions shall be brought to the immediate attention of the City Engineer.
This project has established a DBE goal of TBD%, which includes all certified DBEs at time of Bid.
Bids shall be made on the blank Proposal forms prepared by the Public Works Department and provided herewith. Bids shall give the prices proposed in figures and shall give all other information requested herein. The bidder or its authorized representative shall sign all bid forms as indicated.
Submittal of all bids shall be in accordance with the Notice to Contractors and these Instructions to Bidders.
Bidders must satisfy themselves of the accuracy of the estimate of the quantities of the work to be done by personal examination of the location of the proposed work and by examination of the Plans and Special Provisions of the work. Bidders shall not, at any time after the submission of a bid, dispute or complain of such estimate or assert that there was any misunderstanding in regard to the nature or amount of work to be done. Each bidder shall examine the bidding documents carefully and not later than 2:00 pm on Wednesday, July 15, 2026 shall submit questions through the Question & Answer section of the project on OpenGov for interpretations or correction of any ambiguity, inconsistency, or error which he may discover. Any interpretation or correction by Addendum securely attached to the Contractor’s bid shall be binding. No bidder shall rely upon any interpretation or correction given by any other method. Each bidder represents that its bid is based upon the materials and equipment described in the bidding documents, Plans and Special Provisions.
Before the award of the Contract, any bidder may be required to furnish evidence satisfactory to the City of the necessary facilities, ability and pecuniary resources to fulfill the conditions of the Contract.
Contractor shall prepare and submit a Water Pollution Control Program (WPCP). The WPCP shall conform to the requirements in Section 10-4.06 of the standard Construction Specifications, and these Special Provisions.
The WPCP will be subject to review and approval by the City Engineer. The WPCP shall be submitted to the City Engineer for review at least 5 days prior to the start of construction. During the review process, the Contractor shall revise the WPCP as directed by the City Engineer. In no case will the Contractor be allowed to begin work without an approved WPCP. If the Contractor's method fails to prevent water pollution from entering the waterways, the Contractor shall revise and adjust the control measures and shall be responsible for any cleanup resulting from water pollution originating on the work site.
The Contractor shall furnish all of the labor, materials, tools, equipment and incidentals necessary to implement the water pollution control measures as shown on the Contractor prepared and City approved WPCP. The WPCP shall assume at least one structural Best Management Practice (BMP) between the disturbed area and the drainage channel in the parcel.
All fees and security deposits required for the preparation and completion of the WPCP will be the responsibility of the Contractor.
Measurement and Payment:
Conformance with applicable water pollution control requirements shall be included in the LUMP SUM price. Measurement will be based on the percentage of work completed as determined by the City Engineer and shall include full compensation for furnishing all labor, materials, tools, equipment and incidentals for doing the work involved and no additional compensation shall be allowed therefore.
Contractor shall furnish and install a prefabricated, prefinished, black 2‑rail wrought‑iron fence manufactured by Ameristar (“Montage II Classic” style, 888‑333‑3422) or approved equal. The existing fence shall be removed and the wrought iron fence shall be relocated and installed on the property line. The installation of the wrought iron fence shall require removal of the existing vegetation such as trees, shrubs, and ground cover. The overall fence height shall be 7 feet, except at the headwall located at Draco Drive and Bradshaw Road, where the combined height of the headwall and fence shall be 7 feet. The completed sections (i.e., panels) shall be capable of supporting a 600 lb. load applied at midspan without permanent deformation.
Pickets shall be fabricated from 16‑gauge, 3/4‑inch hot‑rolled structural steel tubing, spaced at 4 inches on center, in accordance with ASTM A513. Rails shall consist of hot‑rolled structural steel square channels measuring 1‑1/2 inches by 1‑1/2 inches by 14 gauge. All rail members shall conform to ASTM A513. Posts shall be 2‑inch by 2‑inch by 11‑gauge hot‑rolled structural steel tubing with flat caps, in accordance with ASTM A513. All metal components shall be hot‑dip galvanized, inside and out, in conformance with ASTM A525‑G90.
Pickets shall be attached to the rails by welded connections. Riveted connections will not be accepted.
The adjacent properties shall be left in a secure manner at the end of each workday. Temporary chain link fence, a minimum of six (6) feet tall shall be used. The contractor shall make the secured area accessible for City maintenance crews at all times.
Measurement and Payment:
Quantities of fence to be paid for will be determined by the LINEAR FOOT from actual measurement of the completed fence. Measurements will be made parallel to the ground slope along the line of the completed fence, deducting the widths of openings.
The contract price paid per linear foot for wrought iron fence includes full compensation for furnishing all labor, materials, tools, equipment, and incidentals, and for doing all the work involved in removing and disposing the existing chain link fence and installing wrought iron fence, complete and in place, including excavation, removal of tailings, clearing and grubbing of trees, shrubs, and ground cover, Portland Concrete Cement footings, coatings, and all necessary hardware, as shown on the plans, as specified in the County of Sacramento Standard Specifications, County of Sacramento Construction Standard Drawing 9-40, State Plan A86, these special provisions, and as directed by the Engineer. Full compensation for temporary fence is included in the contract paid per linear foot for wrought iron fence, and no separate payment will be made therefore.
The City has an approved Quality Assurance Plan.
The Agency publicly opens and reads bids at the time and place shown on the Notice to Bidders as specified in County of Sacramento Standard Construction Specifications Section 2-13.
Bidder shall be licensed in accordance with the Notice to Contractors.
The contractor shall follow the Minority Utilization Goals in the LAPM 12-G for Sacramento County.
Contractor shall furnish utility access gates of the same material as the wrought iron fence. The design and installation of the gate shall be in accordance with County of Sacramento Construction Standard Drawing 9-40. The completed gates shall be capable of supporting a 200 lb. load applied at midspan without permanent deformation.
The gate shall be 7-feet high single swinging gate unless otherwise shown in the plans. The swing movement of the gate shall be configured to allow inward and outward swinging. A gate unit shall be 11-feet long and 7-feet high.
Contractor shall field-verify all gate dimensions prior to fabrication to ensure proper fit. If there is a conflict in the gate dimensions, Contractor shall notify the City Engineer.
Measurement and Payment:
Quantities of gates will be determined from actual count. When more than one gate is placed in an opening, each single unit placed will be counted as a gate. A gate unit complete in place is one gate with all necessary fittings, hardware, and gate and latch posts with braces.
The contract price paid for each gate includes all labor, materials, tools, equipment, and incidentals, and for doing all the work involved in removing and disposing the existing gate and installing wrought iron utility access gate, complete and in place, including excavation, removal of tailings, clearing and grubbing of trees, shrubs, and ground cover, Portland Concrete Cement footings, coatings, and all necessary hardware, as shown on the plans, as specified in the County of Sacramento Standard Specifications, County of Sacramento Construction Standard Drawing 9-40, State Plan A86, these special provisions, and as directed by the Engineer. Full compensation for temporary fence is included in the contract paid per linear foot for wrought iron fence, and no separate payment will be made therefore.
Each bidder shall have listed on the form provided, the name, address and description of the work, of each subcontractor to whom the bidder proposes to sublet portions of the work. For the purpose of this paragraph, attention is directed to the provisions in Section 2-8, “Subcontractors,” and Section 2, “Bid Requirements and Conditions,” and Section 3, “Award and Execution of Contract,” of the Sacramento County Standard Construction Specifications and these Special Provisions with regard to subcontracted portions of the work.
Pursuant to the provisions in Section 1777.1 of the Labor Code, the Labor Commissioner publishes and distributes a list of contractors ineligible to perform work as a subcontractor on public works projects. This list of debarred contractors is available from the Department of Industrial Relations web site at: http://www.dir.ca.gov/DLSE/debar.html.
Contractor shall complete and return Form 12-B of the Local Assistance Procedures Manual included in the Bid Submittal section of this solicitation.
Pedestrian access gate shall be of the same material as the wrought iron fence. The design and installation of the gate shall be in accordance with County of Sacramento Construction Standard Drawing 9-40. The completed gates shall be capable of supporting a 200 lb. load applied at midspan without permanent deformation.
The gate shall be 7-feet high single swinging gate. The swing movement of the gate shall be configured to allow inward and outward swinging. A gate unit shall be 4-feet long and 7-feet high.
Contractor shall field-verify all gate dimensions prior to fabrication to ensure proper fit. If there is a conflict in the gate dimensions, Contractor shall notify the City Engineer.
Measurement and Payment:
Quantities of gates will be determined from actual count. When more than one gate is placed in an opening, each single unit placed will be counted as a gate. A gate unit complete in place is one gate with all necessary fittings, hardware, and gate and latch posts with braces.
The contract price paid for each gate includes all labor, materials, tools, equipment, and incidentals, and for doing all the work involved in removing and disposing the existing gate and installing wrought iron pedestrian access gate, complete and in place, including excavation, removal of tailings, clearing and grubbing of trees, shrubs, and ground cover, Portland Concrete Cement footings, coatings, and all necessary hardware, as shown on the plans, as specified in the County of Sacramento Standard Specifications, County of Sacramento Construction Standard Drawing 9-40, State Plan A86, these special provisions, and as directed by the Engineer.
The Contractor must be properly licensed as a contractor from contract award through Contract acceptance (Public Contract Code § 10164) and as specified in the Standard Construction Specifications General Provisions Section 2-5.
A contractor or subcontractor shall not be qualified to bid on, be listed in a bid proposal, subject to the requirements of Section 4104 of the Public Contract Code, or engage in the performance of any contract for public work, as defined in this chapter, unless currently registered and qualified to perform public work pursuant to Section 1725.5. It is not a violation of this section for an unregistered contractor to submit a bid that is authorized by Section 7029.1 of the Business and Professions Code or by Section 10164 or 20103.5 of the Public Contract Code, provided the contractor is registered to perform public work pursuant to Section 1725.5 at the time the contract is awarded.
Pursuant to Section 1725.5 of the Labor Code, contractors and subcontractors must be registered with the Department of Industrial Relations in order to 1) bid or be listed on a bid for a public works project on or after March 1, 2015, or 2) work on a public works project awarded on or after April 1, 2015.
Contractors and subcontractors can apply and register on the Department of Industrial Relations web site at: http://www.dir.ca.gov/Public-Works/PublicWorksContractorsAndSubcontractors.html
The Federal Training program shall be in accordance with the LAPM 12-G. For the Federal training program, the number of trainees or apprentices is TBD. Submit all documents required in the LAPM 12-G for the Federal Training Program to the City of Rancho Cordova.
Each bidder shall have listed on the form provided, the name, address and description of the work, of each subcontractor to whom the bidder proposes to sublet portions of the work. For the purpose of this paragraph, attention is directed to the provisions in Section 2-8, “Subcontractors,” and Section 2, “Bid Requirements and Conditions,” and Section 3, “Award and Execution of Contract,” of the Sacramento County Standard Construction Specifications and these Special Provisions with regard to subcontracted portions of the work.
Pursuant to the provisions in Section 1777.1 of the Labor Code, the Labor Commissioner publishes and distributes a list of contractors ineligible to perform work as a subcontractor on public works projects. This list of debarred contractors is available from the Department of Industrial Relations web site at: http://www.dir.ca.gov/DLSE/debar.html.
This project does not affect/enter into the National Highway System.
As set forth in Section 7-15 of the Standard Construction Specifications, the time for completion of this contract shall be 25 WORKING DAYS.
The Contractor is required to purchase the traffic signal poles. Due to the time it takes the manufacturer to provide the traffic signal poles, the Contractor will not be penalized working days for the acquisition of traffic signal poles. All other items to be purchase by the Contractor will be subject to the contract working days.
Mesh backing shall conform to the provisions in Section 80, "Fences," of the State Specifications or shall be one-half inch by one-half inch (½” X ½”) expanded metal mesh backing per approved submittal. Mesh is to be powder coated black to match the fence panels.
Unless otherwise stated, the mesh shall be tack welded 12” on center.
Measurement and Payment:
Mesh Backing shall be paid for on a per LINEAR FOOT basis. Measurement will be based on the actual number of linear feet of mesh backing installed. The contract unit price shall include full compensation for furnishing all the labor, materials, tools, equipment, and incidentals for doing all the work of installing the mesh backing on the wrought iron fence and gates per State Plan A86, County of Sacramento Construction Specifications, these special provisions, and as directed by the Engineer.
As set forth in Section 7-15 of the Standard Construction Specifications, the time for completion of this contract shall be 25 WORKING DAYS.
The counting of working days shall begin ten (10) calendar days from the date the Contractor is notified that the contract has been executed for the City of Rancho Cordova.
This work shall consist of, but shall not be limited to, the removal of the existing fence; trimming and/or grinding of existing fence and gate posts; and removal of existing foundations (footings) not included under any other bid item. Work under this bid item shall not include replacement of removed fence, which is covered in Wrought Iron Fence.
Measurement and Payment:
Remove Existing Fence shall be paid for on a per LINEAR FOOT basis. Measurement will be based on the actual number of linear feet of existing fence removed. The contract unit price per linear foot of Remove Existing Fence shall include full compensation for furnishing all the labor, tools, equipment, and incidentals for doing all the work involved in existing fence removal.
Each bidder submitting a bid for any portion of the work contemplated by the documents on which bidding is based, shall execute and attach thereto an affidavit substantially in the form herein provided to the effect that he/she has not entered into collusive agreement with any other person, firm or corporation in regard to any bid submitted.
Each bid must be accompanied by cash, cashier’s check, certified check or Bidder’s Bond made payable to the City of Rancho Cordova in the amount of 10% of the total bid amount, such guaranty to be forfeited should the bidder to whom the contract is awarded fail to enter into the contract.
As set forth in Section 8-10 of the Standard Construction Specifications, the liquidated damages for this contract shall be the sum of Three thousand six-hundred dollars ($3,600) per working day.
Section 7-12.02, “Unavoidable Delays”, of the Standard Construction Specifications shall apply except as herein modified.
No extension of time will be granted for a delay caused by a shortage of materials unless the Contractor furnishes to the Engineer documentary proof that he has made every effort to obtain such materials from all known sources, within reasonable reach of the work in a diligent and timely manner. The documentary proof shall indicate that the inability to obtain such materials, when originally planned, did in fact cause a delay in final completion of the entire work which could not be compensated for by revising the sequence of the Contractor’s operations. The term "Shortage of Materials" as used in this section, shall not apply to materials, articles, parts, or equipment that are processed, made, constructed, fabricated, or manufactured to meet the specific requirements of the contract. Only the physical shortage of material will be considered under these provisions as a cause for extension of time. Delays in obtaining materials due to priority in filling orders will not constitute a shortage of materials.
Each bidder shall complete the Experience/Qualifications Statement included with the Bidder forms.
The bid bonds for the three acceptable lowest bidders shall be retained until the City of Rancho Cordova has accepted the successful bidder. All other Bidder’s Bonds shall be returned to the bidder five (5) working days after bid opening.
The Contractor’s attention is directed to Section 7-8, “Peak Hours, Hours of Darkness, Holidays, and Weekends”, of the Standard Construction Specifications. Construction activities shall be limited to the hours of 8 am to 4:30 pm, unless otherwise directed by the City Engineer.
In accordance with Section 7104 of the Public Contract Code, the Contractor must promptly, and before the following conditions are disturbed, notify the Agency, in writing, of any:
Material that the Contractor believes may be hazardous waste, as defined in Section 25117 of the Health and Safety Code, which is required to be removed to a Class I, Class II, or Class III disposal site in accordance with provisions of existing law.
Subsurface or latent physical conditions at the site differing from those indicated by information about the site made available to bidders prior to the deadline for submitting bids.
Unknown physical conditions at the site of any unusual nature differing materially from those ordinarily encountered and generally recognized as inherent in work of the character provided for in the Contract.
Bid prices shall include everything necessary for the completion of construction and fulfillment of the contract including, but not limited to, furnishing all materials, equipment, tools, plant and other facilities, and all management, superintendence, labor, required testing and other necessary services. Bid prices shall also include allowance for all federal, state and local tax.
The bidder's attention is directed to the provisions in Section 3, "Award and Execution of Contract," of the County of Sacramento Standard Construction Specifications and these Special Provisions for the requirements and conditions concerning award and execution of contract.
Bid protests are to be delivered to the following address:
Dang Bui
City of Rancho Cordova
2729 Prospect Park Drive
Rancho Cordova, CA 95670
The award of the contract, if it is awarded, will be determined based on base bid schedule to the lowest responsive and responsible bidder whose bid complies with all the requirements prescribed as specified in the County of Sacramento Standard Construction Specifications Section 3-1.
The contract shall be executed by the successful bidder and shall be returned, together with the contract bonds, to the Agency so that it is received within 10 days, not including Saturdays, Sundays and legal holidays, after the bidder has received the contract for execution. Failure to do so shall be just cause for forfeiture of the proposal guaranty. The executed contract documents shall be delivered to the following address:
Dang Bui
City of Rancho Cordova
2729 Prospect Park Drive
Rancho Cordova, CA 95670
Promptly notify the Agency’s Engineer if you find either of the following conditions:
Upon your notification, the Engineer investigates job site conditions and:
The U.S. Department of Transportation (DOT) provides a toll-free hotline to report bid rigging activities. Use the hotline to report bid rigging, bidder collusion, and other fraudulent activities. The hotline number is (800) 424-9071. The service is available 24 hours 7 days a week and is confidential and anonymous. The hotline is part of the DOT's effort to identify and investigate highway construction contract fraud and abuse and is operated under the direction of the DOT Inspector General.
The County of Sacramento, Municipal Services Agency, Standard Construction Specifications (Standard Construction Specifications) inclusive of the Standard Drawings, adopted November 2024, and these Special Provisions, shall control all work to be done under this contract. Copies of the Standard Construction Specifications may be obtained from the Municipal Services Agency, Land Division and Site Improvement Review, located in the County Administration Building, 827 Seventh Street, Room 304, Sacramento, California, 95814.
State Standard Specifications and State Standard Plans, when referred to, shall be the 2025 Caltrans Standard Plans and Specifications.
If there is a conflict between the technical provisions or requirements, the following order of precedence shall govern:
The City of Rancho Cordova will promote the formation of a "Partnering" relationship with the Contractor in order to effectively complete the contract to the benefit of both parties. The purpose of this relationship will be to maintain cooperative communication and mutually resolve conflicts at the lowest possible management level.
The Contractor may request the formation of such a "Partnering" relationship by submitting a request in writing to the Engineer after approval of the contract. If the Contractor's request for "Partnering" is approved by the Engineer, scheduling of a "Partnering" workshop, selecting the "Partnering" facilitator and workshop site, and other administrative details shall be as agreed to by both parties.
The costs involved in providing a facilitator and a workshop site will be borne equally by the City of Rancho Cordova and the Contractor. The Contractor shall pay all compensation for the wages and expenses of the facilitator and of the expenses for obtaining the workshop site. The City's share of such costs will be reimbursed to the Contractor in a change order written by the Engineer. Markups will not be added. All other costs associated with the "Partnering" relationship will be borne separately by the party incurring the costs.
The establishment of a "Partnering" relationship will not change or modify the terms and conditions of the contract and will not relieve either party of the legal requirements of the contract.
With the exceptions of the State Specifications and State Standard Plans, all reference to codes, specifications and standards referred to in the contract documents shall mean, and are intended to be, the latest editions, amendment, and/or revision of such referenced documents in effect as of the date of this contract.
The work requirements of authorities shall be the minimum acceptable requirements for the work. Nothing described in these contract documents shall be construed to permit work not conforming to the most stringent of the applicable codes and regulations.
When contract documents call for materials or construction of better quality or larger size than required by codes, laws, rules and regulations, the contract documents shall take precedence.
Attention is directed to Section 7-1.14, "Cooperation," of the State Standard Specifications and these Special Provisions.
Contractor shall fully cooperate with all utilities, including, but not limited to, AT&T, Comcast, Sacramento Municipal Utilities District, Pacific Gas & Electric, Cal American Water Company, Golden State Water Company, Sacramento Area Sewer District, Sacramento County Municipal Services Agency and Sacramento County Department of Transportation.
Contractor shall submit daily Progress Reports to the Engineer via the internet utilizing a web site address VPM @ www.virtual-pm.com managed by the City. This web site, “Virtual Project Manager” will be used exclusively by job site foreman to record daily progress, problems, additions/deletions and or request change orders for review by engineers/inspector and Project Manager. A digital camera and daily use of computer and internet access by job site supervisor are required.
Full compensation for Project Record Keeping, as specified herein, shall be considered as included in the prices paid for the various items of work involved as specified in Section 8 3, “Work to be Done Without Direct Payment,” of the Standard Construction Specifications and no additional compensation will be made therefore.
All equipment, material and supplies called for in the specifications must be new and currently manufactured items, unless otherwise specified. All equipment must be complete and in operation to the satisfaction of the Engineer at the time of acceptance of the work.
All incidental parts which are not shown on the Plans or specified herein and which are necessary to complete the project must be furnished and installed as though such parts were shown on the Plans or specified herein.
All equipment, materials, and supplies to be considered as an approved equal must be submitted to the City for approval no less than fourteen (14) calendar days prior to the bid opening date. If the Engineer finds said equipment, materials, and supplies to be acceptable, an addendum will be issued notifying all bidders no less than four calendar days prior to the bid opening date.
Bidders shall comply with the information provided for the performance and payment bond, as set forth in Section 3-4 of the Standard Construction Specifications.
In the event that hazardous materials are identified prior to construction, or are encountered as an unforeseen condition during construction, the Contractor shall, if necessary, procure and maintain Environmental Liability Insurance as set forth in Section 3-9 of the Standard Construction Specifications. It is acceptable for an environmental Sub-Contractor to provide the required coverage provided the prime Contractor and the City of Rancho Cordova (“City”) are named as "additional insured" and the policy meets the requirements of Section 3-9 of the Standard Construction Specifications. No additional compensation shall be given for the bond or insurances include into bid items.
Contractor shall address all forms or correspondence pertaining to Securities in Lieu items to:
City of Rancho Cordova
Public Works Department
2729 Prospect Park Drive
Rancho Cordova, CA 95670
Contractor shall provide the City with the following information for the purpose of compliance with California Unemployment Insurance Code Section 1088.8 and applicable City codes: Contractor’s name, Contractor’s address, telephone number, social security number, and whether dependent health insurance coverage is available to Contractor.
Attention is directed to the following Notice that is required by Chapter 5 of Division 4 of Title 2, California Code of Regulations.
Your attention is called to the "Nondiscrimination Clause", set forth in Section 7 1.01A (4), "Labor Nondiscrimination," of the State Standard Specifications, which is applicable to all nonexempt state contracts and subcontracts, and to the "Standard California Nondiscrimination Construction Contract Specifications" set forth therein. The Specifications are applicable to all nonexempt state construction contracts and subcontracts of $5,000 or more.
This contract is subject to the Davis-Bacon Federal minimum wage rates and State prevailing wage rates. Pursuant to Section 110 of the Housing and Community Development Act of 1974 and Section 1770, et. seq. of the California Labor Code, the successful bidder and all subcontractors shall pay not less than the prevailing rate of per diem wages as predetermined by the United States Secretary of Labor and by the Director of the California Department of Industrial Relations.
Federal wage determinations for this project can be found on the FHWA website noted below and are on file at City Hall 2729 Prospect Park Drive, Rancho Cordova, CA 95670. If there is a difference between the Federal Minimum Wages and the General Prevailing Wage Determinations as predetermined by the Secretary of Labor and by the Director of the California Department of Industrial Relations for similar classifications of labor, the Contractor and subcontractors shall pay not less than the higher wage rate.
http://www.dir.ca.gov/dirdatabases.html
Davis Bacon Wage Determinations
The Contractors attention is directed to Section 6-1.02, “Prevailing Wage,” of the Sacramento County Standard Construction Specifications. Pursuant to Labor Code Section 1770, the Contractor and the Contractor’s Subcontractors shall pay not less than the prevailing rate of per diem wages, including, but not limited to, overtime, Saturday, Sunday, and holiday work, travel and subsistence, as determined by the Director of the California Department of Industrial Relations pursuant to Labor Code Section 1773.
The Contractors attention is directed to Section 6-1.03, “Payroll Records,” of the Standard Construction Specification. Contractor shall comply with Labor Code Section 1776. Regulations implementing Section 1776 are located in Section 16000 and Sections 16401 through 16403 of Title 8, California Code of Regulations. The Contractor shall be responsible for compliance by the Contractor’s Subcontractors.
Contractor’s failure to comply with state and federal child, family and spousal support requirements regarding a Contractor’s employee or failure to implement lawfully served wage and earnings assignment orders or notices of assignment relating to child, family and spousal support obligations shall constitute a default under this Agreement.
Contractor’s failure to cure such default within 90 days of notice by City shall be grounds for termination of this Agreement.
Five percent (5%) of each progress payment will be retained until the work has been completed and accepted by the Public Works Director of the City of Rancho Cordova. After fifty percent (50%) of the work has been completed, including approved change orders, the Contractor may request that remaining progress payments be made in full and not subject to further withholding of retention. The City will review the progress to date and the remaining work. If it appears that the work will be successfully completed and is progressing on schedule, the City will process subsequent progress payments in full. However, the City reserves the right to withhold 5% retention on any subsequent progress payment if in the opinion of the City the work is no longer progressing on schedule.
A prime contractor or subcontractor shall pay any subcontractor not later than 10 days of receipt of each progress payment in accordance with the provision in Section 7108.5 of the California Business and Professions Code concerning prompt payment to subcontractors. The 10 days is applicable unless a longer period is agreed to in writing. Any delay or postponement of payment over 30 days may take place only for good cause and with the agency’s prior written approval. Any violation of Section 7108.5 shall subject the violating contractor or subcontractor to the penalties, sanctions and other remedies of that section. This requirement shall not be construed to limit or impair any contractual, administrative, or judicial remedies otherwise available to the contractor or subcontractor in the event of a dispute involving late payment or nonpayment by the prime contractor, deficient subcontract performance, or noncompliance by a subcontractor.
Attention is directed to Section 8-3 of the Standard Construction Specifications. All work not mentioned in these Special Provisions shall be constructed in accordance with the Standard Construction Specifications. Payment for work shown on the Plans and specified herein for which there is no item listed on the bid proposal form shall be included in the prices bid for the related items of work to provide a complete job according to the Plans, and no additional compensation will be made therefore.
No compensation adjustments for price index fluctuations for this project will be provided.
No work may take place prior to receipt of the Notice to Proceed. When required by the Special Provisions, the Plans, or by the City Engineer with advanced written notification of at least fifteen (15) working days, the Contractor shall follow the sequence of operations as set forth therein.
Order of Work shall conform to the provisions of Section 8 “Prosecution and Progress” of the State Standard Specifications and these Special Provisions.
Contractor shall submit a staging and sequencing plan for review and approval for all construction operations and as requested by the City. Sequencing plan shall show how traffic and access to streets and residents will be maintained and pedestrian access through the work zone. Contractor shall not close any streets without City approval. The roadway, or portions thereof, can be closed to vehicular traffic as directed in these Special Provisions and as approved by the City Engineer. Sequencing plans shall be such that residents have access to adjacent streets on street parking during work hours.
Trash collection day within the project area is scheduled for Tuesday. The contractor will be allowed to coordinate with the trash collection company (Republic Services) to formulate a trash collection plan that does not restrict the project schedule. The trash collection plan must be mutually agreed upon by the Contractor and trash collection company and then approved by the City Engineer.
Prior to performing any work that requires a lane closure, a Traffic Control Plan, prepared by the Contractor, shall be reviewed and approved by the City of Rancho Cordova. Traffic Control Plan shall include installation of City provided signage specifying funding source.
The Contractor shall not begin work on clearing, grubbing or earthwork operations until a Water Pollution Control Program, prepared by the Contractor, is approved by the City of Rancho Cordova.
At the end of each work day all debris, branches, roots, removed fence, rubbish, and other debris in the work area shall be collected and placed in a suitable disposal bin or pile. Materials to be used later in construction shall be neatly stockpiled. All parts of the work shall be left in a neat and presentable condition at the end of the work shift.
Full compensation for all work in Order of Work within the Project limits shall be considered as included in the prices paid for the various contract items of work and no separate payment will be made therefore.
As stated in Section 7-1 “Beginning of Work”, of the Standard Construction Specifications, the Contractor is advised that, for this project, no field construction work may commence and the counting of working days shall not begin until Notice to Proceed is issued by the City. Work that does not involve field construction such as pre-construction meetings, creation of progress schedules, preparation of Traffic Control Plan, preparation of Water Pollution Control Program, etc., may occur prior to the counting of working days.
The Contractor’s attention is directed to Section 6-21, “Preservation of Property”, of the Standard Construction Specifications. The Contractor shall protect private improvements from damage. On-site private improvements may include, but are not limited to, trees, shrubbery, lawns, irrigation facilities, structures, mailboxes, parking lot pavement, concrete curbing, and driveway pavement. If such objects are damaged, they shall be replaced, repaired and or restored at the Contractor’s expense, to a condition as good or better as when the Contractor entered upon the property, as determined by the Engineer.
During the contract period, the Contractor will not unreasonably interfere with business operations within the project limits or unreasonably delay access to or from private residential driveways. The Contractor, under circumstances within his control, will complete construction in a timely and diligent manner. The Contractor is referred to the “Order of Work” Section and these Special Provisions regarding advance notifications to Project area residents / businesses. The Contractor shall not be allowed to impact or restrict use of any residential or business driveways for more than 48 hours. To meet this schedule the Contractor may submit, for approval by the Engineer, high strength or early strength concrete mixtures or high strength or early strength concrete accelerators or additives.
Work is to be constructed within existing public rights-of-way and within limits of Temporary Construction Agreements as noted on the Plans.
The Contractor shall be responsible for repairing, replacing, or modifying all landscape and irrigation systems within and outside the right-of-way and within Temporary Construction Agreement areas that are damaged, capped, or removed during construction. Damage shall include all that is caused as a result of any and all work associated with the contract. All repairs to both landscaping and irrigation system shall be done in a manner equal to or better than the previously existing conditions. If irrigation systems are damaged during trenching, curb, gutter and sidewalk improvements or other construction activities, the Contractor shall repair the damage within two (2) calendar days in order to maintain full operation of the system. Any loss and/or subsequent replacement of plant material due to damage of the irrigation system or the neglect to repair it promptly shall be the sole responsibility of the Contractor. Landscape replacement or repair shall be completed as soon as it will not be damaged by further construction activities.
Three (3) calendar days prior to beginning work on this project, the Contractor shall be required to notify adjacent or nearby residents / businesses. Residents / businesses shall be notified with a City supplied door hanger. The Contractor shall be responsible for inserting the date on which a section of sidewalk (and driveways) are to be constructed. The door hangers will advise residents / businesses of parking and irrigation restrictions during and immediately in advance of the construction of proposed improvements. Any changes in the Contractor’s schedule shall require that re-notification take place at the Contractor’s expense. It is the Contractor’s responsibility to obtain, at his expense, City-approved door hangers.
Door hangers shall be placed before 1:00 PM three days before beginning work to allow sufficient time for City inspection of the hangers.
The Contractor shall not be allowed to begin work until the residents / businesses within the work area have been notified. The Contractor shall submit for the Engineer the street addresses, the time, and the date the notices were placed prior to commencing work. The Contractor is responsible for providing on the notice the Contractor’s contact phone number(s) to be reached by the residents / businesses after hours and on weekends.
Full compensation for advance notification to residents / businesses shall be included in the prices paid for various contract items of work and no additional compensation will be allowed.
The Contractor shall perform all work outlined in this section without direct payment, as specified in Section 8-3 of the Standard Construction Specifications.
The Contractor’s attention is directed to Section 13-1.01, “Preservation of Property”, of the Standard Construction Specifications. The Contractor shall protect private improvements from damage. On-site private improvements may include, but are not limited to, trees, shrubbery, lawns, irrigation facilities, structures, mailboxes, parking lot pavement, concrete curbing, and driveway pavement. If such objects are damaged, they shall be replaced, repaired and or restored at the Contractor’s expense, to a condition as good or better as when the Contractor entered upon the property, as determined by the Engineer.
During the contract period, the Contractor will not unreasonably interfere with business operations within the project limits or unreasonably delay access to or from private residential driveways. The Contractor, under circumstances within his control, will complete construction in a timely and diligent manner. The Contractor is referred to the “Order of Work” Section and these Special Provisions regarding advance notifications to Project area residents / businesses. The Contractor shall not be allowed to impact or restrict use of any residential or business driveways for more than 48 hours. To meet this schedule the Contractor may submit, for approval by the Engineer, high strength or early strength concrete mixtures or high strength or early strength concrete accelerators or additives at no additional cost to the City.
Work is to be constructed within existing City-owned parcels APN 068-0050-003-0000 and 068-0060-001-0000, public rights-of-way, or within existing easements on APN 068-0050-011-0000.
The Contractor shall be responsible for repairing, replacing, or modifying all landscape and irrigation systems within and outside the right-of-way that are damaged, capped, or removed during construction. Damage shall include all that is caused as a result of any and all work associated with the contract. All repairs to both landscaping and irrigation system shall be done in a manner equal to or better than the previously existing conditions. If irrigation systems are damaged during trenching, curb, gutter and sidewalk improvements or other construction activities, the Contractor shall repair the damage within two (2) calendar days in order to maintain full operation of the system. Any loss and/or subsequent replacement of plant material due to damage of the irrigation system or the neglect to repair it promptly shall be the sole responsibility of the Contractor. Landscape replacement or repair shall be completed as soon as it will not be damaged by further construction activities.
Three (3) calendar days prior to beginning work on this project, the Contractor shall be required to notify adjacent or nearby residents / businesses. Residents / businesses shall be notified with a door hanger. The Contractor shall be responsible for inserting the date on which a section of improvements are to be constructed. The door hangers will advise residents / businesses of parking and irrigation restrictions during and immediately in advance of the construction of proposed improvements. Any changes in the Contractor’s schedule shall require that re-notification take place at the Contractor’s expense. It is the Contractor’s responsibility to obtain, at his expense, City-approved door hangers.
Door hangers shall be placed before 1:00 PM three days before beginning work to allow sufficient time for City inspection of the hangers.
The Contractor shall not be allowed to begin work until the residents / businesses within the work area have been notified. The Contractor shall submit for the Engineer the street addresses, the time, and the date the notices were placed prior to commencing work. The Contractor is responsible for providing on the notice the Contractor’s contact phone number(s) to be reached by the residents / businesses after hours and on weekends.
Full compensation for advance notification to residents / businesses shall be included in the prices paid for various contract items of work and no additional compensation will be allowed.
The Contractor shall perform all work outlined in this section without direct payment, as specified in Section 8-3 of the Standard Construction Specifications.
Except as otherwise noted on the Plans, all work done under this contract shall be conducted within the limits of existing public rights of way and within the limits of existing drainage easements.
Progress schedules will be required for this contract and shall include Preconstruction Conference and Progress Meetings pursuant to Section 7-3 of the Standard Construction Specifications. Progress Schedules must conform to provisions in Section 7-5 of the Standard Construction Specifications.
At the pre-construction meeting the Contractor shall submit to the City Engineer a Schedule of Work for all work included in the project. Full compensation for the preparation of progress schedules and schedule of work will be considered as included in the prices paid for the various contract items of work and no separate payment shall be made therefore.
The Contractor, at the Contractor’s sole expense, must obtain all necessary permits, registrations, certifications, notifications, and licenses for the normal conduct of the Contractor’s business and construction of the Work, and comply with all laws, ordinances, rules and regulations relating to the Work, and to the preservation of the public health and safety.
Unless otherwise noted in the Special Provisions, building, plumbing, heating, electrical, and similar permits that the Contractor is required to obtain from the County’s Building Inspection and Permits Division for County-owned projects are fee exempt and will be obtained by the Agency.
The California Environmental Quality Act of 1970 (CEQA) may be applicable to permits, licenses, and other authorizations that the Contractor must obtain from local agencies in connection with performing the Work. The Contractor must comply with the provisions of CEQA in obtaining the permits, licenses, and other authorizations which will be obtained in time to prevent delays to the Work.
The Contractor must obtain and comply with all required permits, registrations, certifications, and notifications applicable to the Work in conformance with the requirements of Cal/OSHA regulations.
The Contractor must comply with permits, licenses, or other authorizations applicable to the Work obtained by the Agency in conformance with the requirements in CEQA.
The Contractor’s attention is directed to Section 6-11, “Existing Utilities”, of the Standard Construction Specifications and these Special Provisions.
The Contractor shall be responsible for contacting the utility agencies to determine the exact location and depth of existing underground facilities. The Contractor is required to call Underground Service Alert (USA) at 1-800-227-2600 two (2) working days in advance of performing any excavation work. When calling be prepared to supply location, nature of work, start date, company name, company address, and company contact telephone number. The Contractor must mark the physical limits of the area of USA utility location per USA requirements.
All existing utilities within the project limits shall remain in use during construction. The Contractor shall take adequate measures to ensure that his operations do not harm any existing underground facilities not specifically mentioned or shown on the plans.
The Contractor shall use caution during his operations so that existing utility conduits are not disturbed. The Contractor shall repair or replace, at his expense, any utilities damaged by his personnel or equipment during the course of construction work to the satisfaction of the City Engineer.
After the underground service alert (USA) is complete, the first order of work shall be to pothole existing utilities and notify city engineer of any conflicts.
Contractor shall coordinate all utility relocation/repairs/adjustments with the utility owners and shall adjust the construction schedule accordingly.
Full compensation for contacting Underground Service Alert (USA), potholing existing utilities, identifying and notifying the City Engineer of conflicts, and coordinating with the utility companies will be considered as included in the prices paid for the various contract items of work and no separate payment shall be made therefore.
The Contractor shall be responsible for dust control within the project limits and approaches thereto in accordance with Section 17, “Dust Control”, of the Standard Construction Specifications. The Contractor shall conform to all applicable provisions of the referenced section and these Special Provisions. Dust control shall be enforced at all times.
The Contractor shall provide for watering of all exposed or disturbed earth surfaces at least twice daily. The Contractor shall cover stockpiles of debris, soil, sand or other materials that can be blown by the wind. The Contractor shall sweep the construction area and adjacent streets of all mud and dust as needed. Full compensation for dust control will be considered as included in the prices paid for the various contract items of work and no separate payment shall be made thereof.
The Contractor is required to comply with all pertinent rules, regulations, ordinances, and statutes of the local noise ordinances as well as of the local air district. The proposed project may result in the generation of short-term construction-related air emissions, including fugitive dust and exhaust emissions from construction equipment. Fugitive dust, sometimes referred to as windblown dust or PM10, would be the primary short-term construction impact, which may be generated during excavation, grading and hauling activities. However, both fugitive dust and construction equipment exhaust emissions would be temporary and transitory in nature. Standard BMP’s to contain fugitive dust should effectively reduce and control emission impacts during construction.
Disposal of surplus material shall conform to the provisions in Section 18-2.03 of the Standard Construction Specifications and these Special Provisions, and no additional compensation will be made therefore. The Contractor shall comply with all the provisions set forth in the Sacramento County Land Grading and Erosion Control Ordinance when disposing of surplus material within the City of Rancho Cordova or within Sacramento County. Copies of the Land Grading and Erosion Control Ordinance may be obtained from the Municipal Services Agency Land Grading Section in Room 105, 827-7th Street, Sacramento, telephone number (916) 874 6546. Any questions pertaining to the requirements set forth in the Ordinance should be directed to the above office.
All excess excavated material, broken concrete, and any other excess material resulting from the construction shall become the property of the Contractor and shall be properly removed from the right-of-way and no additional compensation will be made therefore.
Construction materials shall not be stockpiled on City streets. If the Contractor requires the use of City streets for construction materials, all construction materials must be removed before the end of the same working day unless approved by City. Contractor must cover the construction materials if a rain event occurs during construction of the project. City streets shall not be used as a staging area for any of the Contractors construction materials or equipment. Full compensation for storage of construction materials shall be included in the prices paid for various contract items of work and no additional compensation will be allowed therefore.
Cobblestones are commonly encountered in City of Rancho Cordova soils. Excavation of the cobblestones may cause sloughing of soils within the excavation. Contractor shall remove cobblestones that protrude more than 2-inches from the excavated face. The Contractor shall stabilize unstable areas immediately if raveling or instability of the soils occurs during the excavation process.
During horizontal direction drilling (HDD) or trenching, cobblestones may be encountered. No separate payment shall be made for HDD or trenching. No separate payment shall be made for removal of the cobblestones, stabilization, or for placement of backfill material within the project limits. Full compensation shall include but not be limited to excavation, stabilization, subgrade preparation, compaction, excess material disposal and incidentals and no additional compensation will be made therefor.
Please provide the following regarding the point of contact for your submittal:
Any person or entity submitting a bid on this project to engage in the business or act in the capacity of a contractor shall be licensed as a contractor in accordance with the provisions of Division 3, Chapter 9 of the California Business and Professions Code. A bid submitted to the City by a contractor who is not licensed as set forth above shall be considered non-responsive and shall be rejected by the City.
Before awarding the contract for this project, the City must verify that the contractor was properly licensed when the contractor submitted his/her bid on this project. In order for the City to verify the license status of a contractor, the contractor, at the time he/she submits his/her bid for the project, shall provide the City his/her contractor's license information.
No bid submitted to the City shall be invalidated by the failure of the bidder to be licensed in accordance with the laws of this state. However, at the time the contract is awarded, the contractor shall be properly licensed in accordance with the laws of this state. The first payment for work or material under any contract shall not be made unless and until the Registrar of Contractors verifies to the City that the records of the Contractors' State License Board indicate that the contractor was properly licensed at the time the contract was awarded. Any bidder or contractor not so licensed shall be subject to all legal penalties imposed by law, including, but not limited to, any appropriate disciplinary action by the Contractors' State License Board. Failure of the bidder to obtain proper and adequate licensing for an award of a contract shall constitute a failure to execute the contract and shall result in the forfeiture of the security of the bidder.
Please enter the California Contractor's License Number for your company.
Enter your California Department of Industrial Relations (DIR) Contractor Registration Number.
Please Note:
If the City is unable to confirm that the bidder/contractor’s DIR registration is current, the City must disqualify the bidder, as required by Labor Code section 1725.5.”
This certification is required by the Equal Employment Opportunity Regulations of the Secretary of Labor (41 CFR 60-1.7(b) (1)), and must be submitted by bidders and proposed subcontractors only in connection with contracts and subcontracts which are subject to the equal opportunity clause. Contracts and subcontracts which are exempt from the equal opportunity clause are set forth in 41 CFR 60-1.5. (Generally only contracts or subcontracts of $10,000 or under are exempt.)
Currently, Standard Form 100 (EEO-1) is the only report required by the Executive Orders or their implementing regulations.
Proposed prime contractors and subcontractors who have participated in a previous contract or subcontract subject to the Executive Orders and have not filed the required reports should note that 41 CFR 60-1.7(b) (1) prevents the award of contracts and subcontracts unless such contractor submits a report covering the delinquent period or such other period specified by the Federal Highway Administration or by the Director, Office of Federal Contract Compliance, U.S. Department of Labor.
Bidder shall confirm whether or not Bidder, and any proposed subcontractors, have participated in previous contract or subcontract subject to the equal opportunity clauses, as required by Executive Orders 10925, 11114, or 11246, and that, where required, have filed with the Joint Reporting Committee, the Director of the Office of Federal Contract Compliance, a Federal Government contracting or administering agency, or the former President's Committee on Equal Employment Opportunity, all reports due under the applicable filling requirements.
In conformance with Public Contract Code Section 10285.1 (Chapter 376, Stats. 1985), the bidder shall declare under penalty of perjury under the laws of the State of California that the bidder "HAS" or "HAS NOT" been convicted within the preceding three years of any offenses referred to in that section, including any charge of fraud, bribery, collusion, conspiracy, or any other act in violation of any state or Federal antitrust law in connection with the bidding upon, award of, or performance of, any public works contract, as defined in Public Contract Code Section 1101, with any public entity, as defined in Public Contract Code Section 1100, including the Regents of the University of California or the Trustees of the California State University. The term "bidder" is understood to include any partner, member, officer, director, responsible managing officer, or responsible managing employee thereof, as referred to in Section 10285.1.
Note: The bidder must select "has" or "has not". The above Statement is part of the Proposal. Submitting this Proposal shall also constitute signature of this Statement. Bidders are cautioned that making a false certification may subject the certifier to criminal prosecution.
In conformance with Public Contract Code Section 10162, the Bidder shall complete, under penalty of perjury, the following questionnaire:
Has the bidder, any officer of the bidder, or any employee of the bidder who has a proprietary interest in the bidder, ever been disqualified, removed, or otherwise prevented from bidding on, or completing a federal, state, or local government project because of a violation of law or a safety regulation?
You have indicated that the bidder, an officer of the bidder, or any employee of the bidder that has a proprietary interest in the bidder, has been disqualified, removed, or otherwise prevented from bidding on or competing a federal, state, or local government project because of a violation of law or a safety regulation.
Please explain the circumstances here.
In conformance with Public Contract Code Section 10232, the Contractor, hereby states under penalty of perjury, that no more than one final unappealable finding of contempt of court by a federal court has been issued against the Contractor within the immediately preceding two year period because of the Contractor's failure to comply with an order of a federal court which orders the Contractor to comply with an order of the National Labor Relations Board.
Note: The above Statement and Questionnaire are part of the Proposal. Submitting this Proposal thereof shall also constitute signature of this Statement and Questionnaire. Bidders are cautioned that making a false certification may subject the certifier to criminal prosecution.
Will you be using subcontractors for this project?
In compliance with the provisions of Section 4100-4114 of the Public Contracts Code of the State of California, and any amendments thereof, each Bidder shall set forth below the name and location of the place of business of each Subcontractor who will perform work or labor or render service to the Contractor in or about the construction of the work or improvement to be performed under these specifications in excess of one-half of one percent (0.5%) of the prime Contractor’s total bid or ten thousand dollars ($10,000.00) whichever is greater. The prime Contractor shall list the portion of the work which will be done by such Subcontractor.
If the Contractor fails to specify a Subcontractor for any portion of the work to be performed under the Contract, the Contractor shall be deemed to have agreed to perform such portion itself, and the Contractor shall not be permitted to subcontract that portion of the work except under the conditions allowed by applicable law.
You have indicated that you will be using subcontractors for this project. Please download the attached form, complete it, and upload it back here as part of your submittal.
Please state the number of years for which the Bidder has been engaged in the contracting of business under its current name.
Please state the number of years of experience the Bidder has in work of a nature similar to that noted in this Bid.
Has the Bidder, as a Contractor, ever failed to satisfactorily complete a Contract awarded to it?
You have indicated that the Bidder, as a Contractor has failed to satisfactorily complete a Contract awarded to it.
Please explain:
Provide information for at least three (3) contracts that have been satisfactorily completed by the Bidder in the last three (3) years.
For each contract, provide the following:
Provide a list of plant and equipment owned by the Bidder, which is definitely available for use on the proposed work as required.
For each item, please provide:
Please download the below documents, complete, and upload.
Please download the below documents, complete, and upload.
NON-COLLUSION AFFIDAVIT
(Title 23 United States Code Section 112 and
Public Contract Code Section 7106)
To the CITY of RANCHO CORDOVA
DEPARTMENT OF PUBLIC WORKS
The bidder confirms that they are the party making the foregoing bid and declares that the bid is not made in the interest of, or on behalf of, any undisclosed person, partnership, company, association, organization, or corporation. The bid is genuine and not collusive or sham. The bidder has not directly or indirectly induced or solicited any other bidder to put in a false or sham bid. The bidder has not directly or indirectly colluded, conspired, connived, or agreed with any bidder or anyone else to put in a sham bid, or to refrain from bidding. The bidder has not in any manner, directly or indirectly, sought by agreement, communication, or conference with anyone to fix the bid price of the bidder or any other bidder, or to fix any overhead, profit, or cost element of the bid price, or of that of any other bidder. All statements contained in the bid are true. The bidder has not, directly or indirectly, submitted his or her bid price or any breakdown thereof, or the contents thereof, or divulged information or data relative thereto, to any corporation, partnership, company, association, organization, bid depository, or to any member or agent thereof, to effectuate a collusive or sham bid, and has not paid, and will not pay, any person or entity for such purpose.
Any person executing this declaration on behalf of a bidder that is a corporation, partnership, joint venture, limited liability company, limited liability partnership, or any other entity, hereby represents that he or she has full power to execute, and does execute, this declaration on behalf of the bidder.
I declare under penalty of perjury under the laws of the State of California that the foregoing is true and correct.
The bidder, under penalty of perjury, certifies that, except as noted below, he/she or any other person associated therewith in the capacity of owner, partner, director, officer, manager:
• is not currently under suspension, debarment, voluntary exclusion, or determination of ineligibility by any Federal agency;
• has not been suspended, debarred, voluntarily excluded or determined ineligible by any Federal agency within the past 3 years;
• does not have a proposed debarment pending; and
• has not been indicted, convicted, or had a civil judgment rendered against it by a court of competent jurisdiction in any matter involving fraud or official misconduct within the past 3 years.
The prospective participant certifies, by submitting this bid or proposal, to the best of his or her knowledge and belief, that:
This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Submission of this certification is a prerequisite for making or entering into this transaction imposed by Section 1352, Title 31, U.S. Code. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure.
The prospective participant also agrees by submitting his or her bid or proposal that he or she shall require that the language of this certification be included in all lower tier subcontracts, which exceed $100,000 and that all such subrecipients shall certify and disclose accordingly.
Please download the below documents, complete, and upload.
The contractor must use the higher wage rate between the Federal Wage Rates and the California Wage Rates.
Pursuant to California Labor Code Section 1720 and following, and Section 1770 and following, the successful bidder shall pay not less than the prevailing rate of per diem wages as determined by the Director of the California Department of Industrial Relations.
Copies of the prevailing wage determinations are on file in the office of the City Clerk.
See the Caltrans Homepage on the internet for the current rates at http://www.dot.ca.gov/hq/LocalPrograms/fedwages.htm or contact your District Local Assistance Engineer for a hard copy.
Please download the below documents, complete, and upload.
Please download the below documents, complete, and upload.
Please download the below documents, complete, and upload.
Some information requested here may overlap with subcontractor information already provided above but this form is for a specific purpose so please repeat any necessary information here.
Is the Contractor or any sub-contractors proposing to use any vehicle and/or equipment subject to California Air Resources Board (CARB) In-Use Off-Road Diesel-Fueled Fleets Regulations (§ 2449 General Requirements)?
Upload CARB Certificate of Reported Compliance
For any additional information requested or required by any of your previously provided answers please upload that additional documentation here.
The party submitting on behalf of the Company noted on the submittal is authorized to submit on behalf of said Company and has provided any authorization showing such if required by this Bid.
In accordance with the Business and Professions Code, the party submitting does hereby, under Penalty of Perjury, certify that the following contractor’s license information is true and correct.
Provide a basic project description in a single sentence or two. Use full sentences.
What is the scheduled day for trash collection in the project area?
Is there federal funding involved in this project? And/or will the federal terms and conditions apply?
NOTE: If you indicate that there are federal terms and conditions that apply, then be sure to carefully review the Federal Provisions section of this document and remove exceptions or restrictions that do not apply to your individual project.
You have indicated that federal terms and conditions apply to this project. What is the Federal Aid Project ID for this project?
You have indicated that federal terms and conditions apply for this project.
In percentage, what is the DBE Goal or Requirement for this project? If there is no goal or requirement then put a "0" to indicate 0%.
NOTE: DO NOT ENTER THE % SIGN, JUST ENTER THE NUMBER INCLUDING ANY DECIMAL PLACES (ex: 4.5)
In the Federal Trainee Program clause, how many trainees or apprentices do you wish to state.
Please write out the number in text and show numeric value.
EXAMPLE (5):
five (5)
What is the estimated value or cost of this project?
NOTE: Just enter a number, DO NOT enter the dollar sign.
Is the estimated value for this project close to or over One Million Dollars ($1,000,000)?
What is the contractor's license requirement for the prime contractor for this project?
Type it it out here how you want it to show in the document as if you are filling in the highlighted area:
CONTRACTOR LICENSE REQUIRE: <LICENSE>
What is the number of working days for this project starting from the date of the Notice to Proceed or a date otherwise identified to the contractor as the start of work?
Please input using the format of both written and numerical value:
Ex: One Hundred Twenty (120)
Complete the following by filling in the highlighted area:
The lowest bid will be determined based on _________.
What is the per day amount for liquidated damages that you wish to state in this solicitation?
Be sure to format with both written and numerical amount.
EX: Five Hundred Dollars ($500)
SLED stands for State, Local, and Education. These are solicitations issued by state governments, counties, cities, school districts, utilities, and higher education institutions — as opposed to federal agencies.
SamSearch Platform
AI-powered intelligence for the right opportunities, the right leads, and the right time.